Site work and paving for a mixed-use development in Stockton, California. Completed plans call for site work for a educational facility; sidewalk / parking lot; and for paving for a sidewalk / parking lot.

Stockton Unified School District Request for Qualifications and Proposals (RFQ/P) #'S: 25.002, 25.003, 25.004 and 25.005 Lease-leaseback Construction Services Stockton Unified School District ("District") is seeking proposals from qualified persons, firms, partnerships, corporations, associations, or professional organizations to provide constructability review, value engineering, master scheduling, cost estimating, budgeting, and construction services for the Development and Construction of Fabric Shade Structures at Various Sites Project ("Project"), in accordance with the lease-leaseback structure set forth in Education Code section 17406, et seq. Project Description and Scope of Services A. General The purpose of this RFQ/P is to select a qualified person, firm, partnership, corporation, association, or professional organization to provide constructability review, value engineering, master scheduling, cost estimating, budgeting, and construction services for the development and construction for the Construction of Fabric Shade Structures at Various Sites Project and Required Accessible Path of Travel and Parking Lot Upgrades ("Project"), in accordance with the lease-leaseback structure set forth in Education Code section 17406 et seq. Selected developer shall have experience with the construction of public school facilities and complying with the requirements of the Office of Public School Construction ("OPSC"), the Division of the State Architect ("DSA"), and Title 24 of the California Code of Regulations. To submit a proposal, Respondents must be properly licensed by the California Contractors State License Board and registered with the Department of Industrial Relations ("DIR") as required by law. Only Respondents who have been prequalified by the District in accordance with Public Contract Code section 20111.6 are eligible to respond to this RFQ/P. The selected developer will be required to comply with the prevailing wage requirements, the skilled and trained workforce requirements, and the District's bonding and insurance requirements. This Project is funded in whole or in part with federal funds, and therefore the selected developer shall comply with the Davis-Bacon Act, applicable reporting requirements such as APPENDICES C-4 and C-5, and any other applicable requirements for federal funding. The selected developer shall be required to work cooperatively with District staff, the Governing Board, all other technical consultants, the architect, the project inspector, and any program and/or construction manager, if any, retained by the District for the Project, citizens' oversight committee, other District committees, and the community at large to deliver a timely and professional completion of the Project. The Project is further defined in the attached APPENDIX A, along with the District's construction budget and schedule for the Project. Respondents' Proposal shall include Respondent's proposed fees and costs to perform the Project if the Respondent is awarded the contract. The District intends to select one Respondent per GROUP that best meets the District's needs to perform the Project. The criteria on which the District makes its determination will be based on the District's adopted best value methodology and criteria provided in this RFQ/P. B. Scope of Work Although the final scope of work will be negotiated in the executed Agreement (defined below at subparagraph G), the selected developer shall be responsible for performing the following scope of work, at a minimum: Preconstruction Services: 1. Review design and support documentation for content, constructability, completeness, scheduling, clarity, consistency, and coordination. 2. Undertake value-engineering analysis and prepare reports with recommendations to District and Architect of Record to maintain established program budget and specifications. 3. Provide detailed cost estimates. 4. Expedite design reviews, including modifications, if any, based on value analysis. 5. Provide a proposed Guaranteed Maximum Price ("GMP") for the construction of the project with identified subcontractor bids and self-performed work. Construction Services: 1. Construction of the Project. 2. Coordination of record drawings and specifications. 3. Compilation of operations and maintenance manuals, warranties/guarantees, and certificates. 4. Obtaining occupancy permits and coordinating testing, documentation, and governmental inspections and approvals. 5. Preparation of accounting and closeout reports and occupancy plan reports. 6. Other responsibilities as necessary for the completion of the program. Project Name: Construction of Fabric Shade Structures at Various Sites Project There are FOUR (4) individual projects included in this RFQ/P. Respondents may submit on all projects, an individual project or a combination of projects. The District has initiated the purchase of the fabric shade components directly from USA Shade. Dollar amounts for each GROUP A, B, C & D are listed below. Product will be delivered directly to the District. GROUP A: RFQ/P Number: 25.002 10 (Ten) School Sites Construction Estimate: $ 809,491 Materials already purchased: $1,080,400 GROUP B: RFQ/P Number: 25.003 15 (Fifteen) School Sites Construction Estimate: $1,273,316 Materials already purchased: $1,479,000 GROUP C: RFQ/P Number: 25.004 20 (Twenty) School Sites Construction Estimate: $1,703,628 Materials already purchased: $1,931,800 GROUP D: RFQ/P Number: 25.005 7 (Seven) School Sites Construction Estimate: $ 917,566 Materials already purchased: $ 598,300 Question Deadline 09/03/2024 at 3:00 PM PT Questions regarding this RFQ/P may be directed to Peter I. Parenti, Peter@trigroup.us, and must be submitted in writing. The Request for Qualifications and Proposals ("RFQ/P"), which includes instructions for its completion, is enclosed for your consideration. Respondents to this RFQ/P shall submit a completed Statement of Qualifications ("SOQ") along with the Proposal (collectively "RFQ/P Packet"). This Project is subject to labor compliance monitoring and enforcement of compliance with prevailing wage requirements by the Department of Industrial Relations pursuant to Labor Code 1771.4, and skilled and trained workforce requirement pursuant to Public Contract Code 2600. Contractors of all tiers must be currently registered and qualified to perform public work pursuant to Labor Code 1725.5. All Respondents must be prequalified by the District in accordance with Public Contract Code 20111.6. First tier electrical, mechanical and plumbing subcontractors must be prequalified prior to the time subcontractor bids are submitted. September 5, 2024 Last day for District to issue addenda to answer questions/clarifications. Week of September 9, 2024 Release of shortlist of qualified Respondents and interview notifications if necessary. September 24, 2024 Board Award of LLB Contract. September 25, 2024 Notice to selected developer to commence contract negotiation. Each submittal must conform and be responsive to the requirements set forth in this RFQ/P. The District reserves the right to waive any informalities or irregularities in the RFQ/P Packets. The District also reserves the right to reject any and all RFQ/P Packets and to negotiate contract terms with one or more Respondents. The District retains the sole discretion to determine issues of compliance and to determine whether a respondent is responsive, responsible, and qualified. The District hereby notifies all Respondents that it will affirmatively insure that, in any contract entered into pursuant to this advertisement, no respondent will be discriminated against on the grounds of race, religious creed, color, national origin, ancestry, physical disability, mental disability, reproductive health decisionmaking, medical condition, genetic information, marital status, sex, gender, gender identity, gender expression, age, sexual orientation, or veteran or military status on consideration for the award. Completion Date: January 28, 2025