Site work, paving and new construction of a mixed-use development in Corpus Christi, Texas. Completed plans call for the construction of a playground / park / athletic field; for site work for a playground / park / athletic field; for paving for a playground / park / athletic field; sidewalk / parking lot; sidewalk / parking lot; pre-engineered storage facility; pre-engineered storage facility; sidewalk / parking lot; and pre-engineered storage facility.

Award: Bonco LLC for $847,597.77 The Commissioners Court of Nueces County (hereinafter called the "County") will accept sealed competitive bids for: WORKOUT STATION STRUCTURE FOR HAZEL BAZEMORE PARK, 4343 Co. Rd .69, Corpus Christi, TX 78410 in accordance with the Drawings, Specifications, and other Contract Documents prepared by LJA Engineering. Scope of Work The Scope of Work (SOW) for this project is detailed fully in the attachments below: o Attachment E - Specifications o Attachment F - Plan Drawings Bidder agrees that if his/her Bid is accepted by the County, he will complete all work called for under the Contract Documents on or before 180 calendar days after the date of the Notice to Proceed for the Base Bid; and if the work is not completed by such time, he/she agrees to pay to the County as liquidated damages, the sum of Three Hundred Dollars and no/100 ($300.00) for each calendar day after such time that the work remains incomplete, calculated in accordance with the provisions of the Contract Documents. SOW for Base Bid summarizes as follows: The scope of work for the Base Bid consists of the following: The scope of work for the Hazel Bazemore Park project includes a pre-manufactured metal building, including foundation, electrical services, exterior and interior building lighting, ceiling fan, overhead glass door, rolling doors, windows, double doors and nine (9) exercise equipment units. Provide new concrete walkway surface connectivity with staircase, handrails, ADA ramps within the existing restroom, playground, splash pad and new gym building, also playground mulch replacement and other miscellaneous items to complete the work. The scope of work for Additive Bid # 1 consists of the following: The scope of work includes five (5) additional exercise equipment units, to be installed inside the new pre-manufactured metal building and other miscellaneous items to complete the work. The Contractor shall provide all tools and equipment that are necessary to complete the project in its entirety. All work shall be in accordance with the scope of work. All materials used for the project shall be equal to or better than the existing materials quality. The Contractor will be responsible for removal and disposal of all demolished materials and debris from the work area. The Contractor shall take proper care to avoid unnecessary noise, clatter or obstructions in walkways, sidewalks, and roadways. The Contractor shall not interfere with use or safe passage to and from building and adjacent facilities. Nueces County does not provide project estimated cost, in order to receive the lowest & best bid for our taxpayers. Time is of the essence. Failure to complete the Project within the contract time, except as such time may be extended by delays approved by County, will subject the Bidder to whom the contract is awarded, liability for damages, as provided in the Conditions of the Contract. Contract Administrator: Nueces County Community Service and Inland Parks Director, Edward Herrera will serve as the contract administrator for this project. Note: The U.S. Department of Treasury will not extend its deadlines. All federally funded work/assignments must be completed and in full use on or before December 31, 2026. Last Day for Questions: October 23, 2024 by 3:00 PM Nueces County Purchasing Agent will allow written questions and requests for clarification of this solicitation. Questions must be submitted via online.