Site work and renovation of a transportation facility in Longview, Texas. Completed plans call for the renovation of a transportation facility; and for site work for a transportation facility.

East Texas Regional Airport, Longview, Texas - Rooftop Hvac Screening Wall Gregg County, Texas will suffer financial loss if the project is not completed within the contract time. Contract time is 120 calendar days. Each prime contractor or its surety shall be liable for and shall pay to Gregg County the sum of one thousand dollars ($1,000.00) per calendar day that the project remains incomplete beyond the expiration of the contract time. Bid date notes. Respondents submitting via mail services shall send two (2) sets of SEALED documents: one with original signatures and one copy. Respondent shall also submit one flash drive (jump, thumb) with a copy of their bid packet downloaded. Respondent submitting online Mail & Delivery of Proposals: If responses are sent by mail to the Purchasing Department, the Respondent shall be responsible for actual delivery of the bid submission to the Gregg County Purchasing Department before the advertised due date and time. If mail is delayed either in the postal service or in the internal mail system of Gregg County beyond the date and hour set for the bid opening, responses thus delayed will not be considered and will be disposed of as authorized. Late bids/proposals: Any responses received after the date and/or hour set for in this bid document will not be accepted. The late Respondent will be notified and will advise Gregg County Purchasing as to the disposition by either pick up, return at bidder's expense, or destroyed with written authorization. Title VI Solicitation Notice Gregg County, in accordance with the provisions of Title VI of the Civil Rights Act of 1964 (78 Stat. 252, 42 USC 2000d to 2000d-4) and the Regulations, hereby notifies all bidders or offerors that it will affirmatively ensure that for any contract entered into pursuant to this advertisement, disadvantaged business enterprises will be afforded full and fair opportunity to submit bids in response to this invitation and no businesses will be discriminated against on the grounds of race, color, national origin (including limited English proficiency), creed, sex (including sexual orientation and gender identity), age, or disability in consideration for an award. *The value for this project is based on a financial range. The value is listed as the highest possible cost from the range provided by a stakeholder or official project document. Estimate: $215,000 to $245,000 Scope Rooftop HVAC Screening Wall. The Work consists of the following: Project consists of all work associated with the installation of a new rooftop screen wall at the East Texas Regional Airport in Longview, Texas. Selective demolition of existing wall construction will be required. Miscellaneous steel will be used to attach the new screen wall. Some portions of existing EIFS will be repaired while others will be removed. New wall supported ladders will be installed. The project will include some electrical work to remove and then replace exterior lighting fixtures. Project will be constructed under a single prime contract. No pre-bid will be held for this project. Gregg County reserves the right to accept or reject in whole or in part any bid received and to waive any irregularities or formalities in the best interest of Gregg County.