Renovation of an educational facility in Galloway, New Jersey. Working plans call for the renovation of a educational facility.

**As of December 3, 2024, project is cancelled. No definite date for the rebid.** The Atlantic Community Charter School solicits proposals through the Request for Proposal (RFP) process in accordance with New Jersey Public School Contracts Law and Federal Code 2 CFR 200.320 (b) (2). PROPOSAL NO. RFP 2025-09 Installation of Multi-Purpose Floor Proposals may also be submitted to the School Business Administrator/Board Secretary or his designee at the proposal opening meeting, in the Board Meeting Room, prior to the advertised date and time. Proposals that are submitted are to be sealed. Proposals must be submitted in duplicate on the submittal forms as provided and in the manner designated. The Board requires one original and one duplicate copy of the proposal package. The duplicate is necessary for processing the proposals. Respondents should also keep a complete copy of the proposal packet, exactly as submitted. Failure to properly label the proposal envelope may lead to the rejection of the proposal. The Board does not accept electronic (e-mail) submissions of bids or proposals. On the advertised date and time, the School Business Administrator/Board Secretary shall publicly receive and open all proposals. No proposals shall be received after the time designated in the advertisement. (N.J.S.A. 18A:18A-21(b)). All respondents are required to comply with the requirements of N.J.S.A. 10:5-31 et seq., and N.J.A.C. 17:27 et seq. Statement of Ownership Requirement: Pursuant to N.J.S.A. 52:25-24.2, Bidders/respondents shall submit a statement setting forth the names and addresses of all persons and entities that own ten percent or more of its stock or interest of any type at all levels of ownership. A Non-Collusion Affidavit and a Contractor Questionnaire/Certification also must be filed with the proposal. The proposal package will also include other documents that must be completed and returned with the proposal. Failure to complete and submit all required forms may be cause for disqualification and rejection of the proposal. The Board reserves the right to reject any non-responsive proposals or all proposals, pursuant to N.J.S.A. 18A:18A-22, and to waive minor informalities or non-material exceptions, that may be in the best interest of the Board. PUBLIC NOTICE: PROCURING GOODS AND SERVICES FINANCED WITH FEDERAL FUNDS The Atlantic Community Charter School hereby provides public notice that Federal funds will not be used to procure the goods/services as outlined in the bid specifications. The percentage of the cost of the goods/services are outlined below: Federal Program Percentage of the Total Cost of Bid N/A 0% CERTIFICATIONS SECTION; FEDERAL CONTRACT REQUIREMENTS As a requirement for submission of the proposal, all respondents are to read the Certifications Section for Federal Contract Requirements, found at the end of the RFP package. Respondents shall be responsible for the completion, execution, and submission of all required certification documents.