Site work and paving for a civil project in Port St Joe, Florida. Completed plans call for site work for a road / highway; for paving for a road / highway; and water / sewer project.

This project consists of constructing drainage improvements at the intersection of Avenue C and Battle Street located in Port St. Joe, Florida. The City of Port St. Joe Will Receive Sealed Bids From Any Qualified Person, Company or Corporation Interested in Constructing: Avenue C and Battle Street Intersection This Project Consists of Constructing Drainage Improvements at the Intersection Of Avenue C and Battle Street Located in Port St. Joe, Florida. All Bidders Shall Be Fdot Qualified Per Section 2-1 of the Fdot Standard Specifications for Road and Bridge Construction, Latest Edition in the Following Work Classes: Grading, Drainage, Flexible Paving, and Hot Plant Mix-bituminous Course. The Completion Date for This Project Will Be 30 Days for Substantial Completion And 45 Days for Final Completion From the Date of the Notice to Proceed Presented to the Successful Bidder. Liquidated Damages for Failure to Complete. The Project on the Specified Date Will Be Set at $500.00 Per Day. Questions Regarding the Project Must Be Submitted in Writing to Josh Stephens at Jstephens@dewberry.com Prior to Friday, December 27, 2024. Please Indicate on the Envelope That This is a Sealed Bid, for Rfp 2024-24 Avenue C and Battle Street Intersection . The City of Port St. Joe Reserves the Right to Waive Informalities in Any Bid, to Accept and/or Reject Any or All Bids, and to Accept the Bid That in Their Judgment Will Be in Their Best Interest. All Bids Shall Remain Firm for a Period of Sixty Days After the Opening. All Bidders Shall Comply With All Applicable State and Local Laws Concerning Licensing Registration and Regulation of Contractors Doing Business to the State of Florida.