Renovation of a fire / police facility in Orlando, Florida. Completed plans call for the renovation of a fire / police facility.

Orange County, Florida, henceforth referred to as the County is accepting sealed bids for Fire Stations Security Camera Upgrades Phase 1 (Y25-739) Design and construction of security camera systems for 15 stations and their staff parking areas. The Estimated Cost for this project is $425,000.00 It is the respondent's responsibility to ensure they commence their upload efforts timely to meet the submission deadline. The County shall not be responsible for delays caused by any occurrence, including the respondent's network delays, bandwidth issues, internet outages, or technical difficulties. Question Deadline 01/16/2025 at 4:00 PM ET Untimely questions are unable to be submitted in the question and answer module, thereafter respondents raising critical concerns must email gerson.vazquezgonzalez@ocfl.net. Respondents are instructed not to contact the initiating division directly. Answers for timely questions will be addressed electronically or as an addenda to this solicitation depending on volume, participants are encouraged to subscribe as a follower and monitor all notifications. Consideration for modification or alteration of the documents contained in this solicitation shall be requested during the specified question period, before the applicable deadline. No oral interpretation of the meaning of the plans, specifications, or other Contract documents shall be considered binding. The County shall be bound by information and statements only when such statements are written and executed under the authority of the Manager, Procurement Division. Beyond questions and answers, any and all modifications, clarifications, interpretations and supplemental instructions will be in the form of a written addendum which, if issued, will be available for obtain. All addenda and questions/answers so issued shall become part of the Contract Documents and receipt shall be acknowledged as specified herein. This provision exists solely for the convenience and administrative efficiency of Orange County. No respondent or other third party gains any rights by virtue of this provision or the application thereof, nor shall any respondent or third party have any standing to sue or cause of action arising there from. Critical clarifications may be made via addenda, however, untimely questions may not be considered. Should the Contractor fail to substantially complete all Work under this Contract and make the project available for beneficial use on or before the date stipulated for Substantial Completion (or such later date as may result from extension of time granted by County), he shall pay and/or the County may retain from the compensation otherwise to be paid to the Contractor, as liquidated damages, the sum of $150.00 for each consecutive calendar day that terms of the Contract remain unfulfilled beyond date allowed by the Contract, which sum is agreed upon as a reasonable and proper measure of damages which County will sustain per diem by failure of Contractor to complete work within time as stipulated; it being recognized by County and Contractor that the injury to County which could result from a failure of Contractor to complete on schedule is uncertain and cannot be computed exactly. In no way shall costs for liquidated damages be construed as a penalty on the Contractor. For each consecutive calendar day that the work remains incomplete after the date established for Final Completion, the County will retain from the compensation otherwise to be paid to the Contractor the sum of $150.00. This amount is the mutually agreed upon minimum measure of damages the County will sustain by failure of the Contractor to complete all remedial work, correct deficient work, clean up the project and other miscellaneous tasks as required to complete all Work specified and this amount of liquidated damages is in addition to the liquidated damages prescribed above for failure to timely achieve Substantial Completion.