Renovation of a mixed-use development in Omaha, Nebraska. Completed plans call for the renovation of a medical facility.

The Contractor shall develop a Critical Path Method (CPM) plan and schedule demonstrating fulfillment of the contract requirements (Project Schedule), and shall keep the Project Schedule up-to-date in accordance with the requirements of this section and shall utilize the plan for scheduling, coordinating and monitoring work under this contract (including all activities of subcontractors, equipment vendors and suppliers). Conventional Critical Path Method (CPM) technique shall be utilized to satisfy both time and cost applications. Site Visit General Information 1. Solicitation Number: 36C26325B0008 2. Project Number: 636-25-30 3. Title: Emergency Electrical System Upgrades (NWI) 4. Solicitation Release Date: March 19, 2025 5. Questions Due Date: April 8, 2025 at 3:00 PM CT; Answers to questions will be posted in an amendment that will be posted to Contract Opportunities. 6. Proposal Due Date and Time: April 22, 2025 at 10:00 AM CT 7. Payment Bond/Performance Bond are required 8. Email Address of Contract Specialist: tommy.opal@va.gov 9. Email Address of Contracting Officer: angelique.mabley@va.gov 10.Period of Performance: 365 Calendar Days after Notice to Proceed (NTP) 11.Work shall begin within 10 calendar days of Issuance of NTP. 12.Magnitude of Construction: Between $500,000.00 and $1,000,000.00 13.Set aside for Service-Disabled Veteran-Owned Small Business (SDVOSB) 14.This is a Firm Fixed Price Lump Sum Proposal. 15.When you are onsite, you are allowed to take pictures. However, please avoid taking pictures of employees and/or patients. 16.If you have further questions during or after the site visit, please email them to the Contract Specialist and copy the Contracting Officer. Answers will be posted in an amendment that will be posted to Contract Opportunities. Any comments made during the site visit will not change the requirements of the solicitation. All changes will only be made by amendment to the solicitation. *The value for this project is based on a financial range. The value is listed as the highest possible cost from the range provided by a stakeholder or official project document.