Renovation of a mixed-use development in Daytona Beach, Florida. Completed plans call for the renovation of a conference / convention center; and parking garage.

**As of June 25,2025, this project has not yet been awarded. A timeline for the award has not yet been established.** The County is seeking a turnkey wireless solution for the Ocean Center that includes system design, hardware and software installation, and low-voltage cabling. The awarded Contractor shall be responsible for replacing core fiber infrastructure, providing coverage across the facility, and ensuring scalability for future growth. Service Locations Street addresses of locations: Ocean Center - 101 N. Atlantic Avenue, Dayona Beach, Florida 32118 Ocean Center Garage - 701 Earl Street, Daytona Beach, Florida 32118 Contact Information John Duckworth Sr. Procurement Analyst 123 W. Indiana Avenue Room 302 DeLand, FL 32720 Email: jduckworth@volusia.org Phone: (386) 822-5792 Time is of the essence for this project. Any delays from the dates contained in the Agreement issued to the awarded Respondent shall inconvenience the Public and result in monetary losses and damages to the County. The losses and damages shall be difficult to determine. In the event that the deliverables are not provided by the date set in the resulting Agreement, there shall be deducted, as agreed, fixed liquidated damages from the Agreement price being paid by the County of Volusia. This computed sum shall be One thousand Dollars ($1,000) per day, including Saturdays and Sundays. The County reserves the right to accept or reject any or all proposals received as a result of this Solicitation, or to negotiate separately with competing Respondents, and to waive any informalities, defects, or irregularities in any proposal, or to accept that proposal or proposals, which in the judgment of the proper officials, is in the best interest of the County. Question Deadline 04/29/2025 at 11:59 PM ET Questions and exceptions shall be submitted. Thereafter, no further questions or exceptions will be accepted or reviewed by the County and Respondents' right to submit questions or exceptions will terminate and any questions or exceptions not previously made shall be deemed waived. Oral representations will not be binding on the County. All information in this Solicitation, including information provided through electronically. QA - 4/28/25 Shortlist Confirmed