Renovation of an educational facility in Byron, Georgia. Working plans call for the renovation of a educational facility.

The projects will include site work, building construction, selective demolition, renovation/modification of existing facilities. Question Deadline 09/05/2025 Any questions regarding this Request shall be submitted in writing to the Architect at the address listed below or email. Architect will respond to any respondents questions received within four calendar days of the submittal due date. The Construction Management at Risk services shall include a Pre-Construction Design Phase and a Construction Phase. The CM will provide comprehensive administration and management of all aspects of the construction of the project and will work in concert with the A/E towards the successful completion of the project on schedule, at or less than budgeted costs, meeting or exceeding standards stipulated by the construction documents, and in adherence with standards required by local authorities and other agencies having jurisdiction. The CM, either through in-house staff or outside consultant/contractors, will serve as a construction manager/contractor or provide all construction services and activities necessary for the design, construction, and occupancy of the project. The services described in this Request are representative of the services required but do not constitute a comprehensive specification. A comprehensive specification of the Scope of Services required is contained in the proposed Construction Management Agreement that will be issued to all short-listed respondents. Any questions regarding this Request shall be submitted in writing to the Architect at the address listed below or email. Architect will respond to any respondent's questions received within four calendar days of the submittal due date. One (1) Digital Copy sent directly to: SP Design Group Architects and Engineers, Inc. Attention: Rodney W. Wilson rww@spdesigngrp.com P.O. Box 6254 (31208) 5191 Columbus Road Macon, GA 31206 Project Schedule The Architect (A/E) has prepared a Preliminary Total Project Schedule that targets July 15, 2026 for substantial completion of the scope of work. The CM will be responsible for reviewing and incorporating milestones shown in the Preliminary Total Project Schedule into his own Total Project Schedule. Construction Budget The preliminary construction budget of the scope of work is $7,000,000. Final project SCL to be determined by PEACH COUNTY BOARD OF EDUCATION at the completion of pre-construction services by the successful CM. It is the sole responsibility of the respondents to assure delivery to the appropriate party. The owner cannot accept responsibility for incorrect delivery, regardless of reason. No submittals will be accepted after the time stipulated above. Qualification's submittal will not be accepted via facsimile. The Owner reserves the right to reject any or all Proposals received. The Owner is not obligated to request clarifications or additional information but may do so at its discretion. The Owner reserves the right to extend the deadline for submittals.