Site work for a playground / park / athletic field in Birmingham, Alabama. Completed plans call for site work for a playground / park / athletic field.

Tennis Courts Replacement, Birmingham, Alabama General Contractors Are Required to Prequalify Prior to Requesting Bid Documents. In Reviewing the Submittals, Emphasis Will Be Placed on Your Firm's Experience With Projects Similar in Size and Type to This Project. A Written List of Contractors Receiving Prequalification to Bid This Project Will Be Issued to All Who Requested Consideration on September 5, 2025. A Cashier's Check or Bid Bond Payable to Lawson State Community College in an Amount Not Less Than Five (5) Percent of the Amount of the Bid, but in No Event More Than $10,000, Must Accompany the Bidder's Proposal. Performance and Payment Bonds and Evidence of Insurance Required in the Bid Documents Will Be Required at the Signing of the Contract. General Contractors Are Required to Prequalify Prior to Requesting Bid Documents. Prequalification Proposal Requirements May Be Obtained From the Architect, by Request by E-mail: Cbaker@wardscottmorris.com, to Christy Baker. Return One (1) Electronic Copy of the Completed Packet to Cbaker@wardscottmorris.com Issued to Each Trade Contract Bidder Submitting a Bona Fide Bid, Upon Return of Documents in Good Condition Within Ten Days of Bid Date. Other Sets for Contractors, and Sets for Dealers, May Be Obtained With the Same Deposit, Which Will Be Refunded as Above, Less Cost of Printing, Reproduction, Handling, and Distribution. Electronic Pdf Copies of Bid Documents May Be Procured Free of Charge. Bid Bonds Are to Be Issued by an Acceptable Bonding Company Licensed to Do Business in the State, With a Power of Attorney, to Confess Judgment Thereon, With the Understanding That It Shall Guarantee That the Bidder Shall Not Withdraw His Bid for the Guarantee Period of Sixty (60) Days After the Scheduled Closing Time for the Receipt of Bids; That if His Bid is Accepted, He Will Enter Into a Formal Contract With the Owner, and That in the Event of a Withdrawal of Said Bid Within Said Period, or the Failure to Enter Into Said Contract Within the Time Specified, the Bidder Shall Be Liable to the Owner for the Full Amount of the Bid Guarantee as Liquidated Damages and Not as a Forfeit or as a Penalty. The Bid Bond and Certified Checks on Unsuccessful Bidders Will Be Returned Upon Awarding the Contract or Rejection of All Bids, in No Event, Later Than the Number of Days in the Guarantee Period From the Opening of Proposals. That of the Successful Bidder Will Be Returned When Formal Contract and Bonds Are Accepted and Approved. Amounts Exceeding That Established by the State Licensing Board for General Contractors Must Be Licensed Under the Provisions of Title 34, Chapter 8, Code of Alabama, 1975, and Must Show Evidence of License Before Bidding or Bid Will Not Be Received or Considered by the Architect; the Bidder Shall Show Such Evidence by Clearly Displaying His or Her Current License Number on the Outside of the Sealed Envelope in Which the Proposal is Delivered. The Owner Reserves the Right to Reject Any or All Proposals and to Waive Technical Errors if, in the Owner's Judgment, the Best Interests of the Owner Will Thereby Be Promoted. Any Questions Concerning the Pre-bid Conference Shall Be Directed to the Architect. SQUARE FOOTAGE: 20,516