Renovation of a municipal facility in Apalachicola, Florida. Completed plans call for the renovation of a municipal facility.

The scope includes demolition of existing walls, doors, ramps, casework, and carpet flooring in the courtroom, as well as removal and storage of existing seating for later reinstallation. New work includes construction of wood-framed platforms with plywood and oak trim, new ramps, wall partitions with gypsum board and sound attenuation insulation, and installation of solid surface countertops with oak wood tops and trim. All casework shall adhere to AWI standards. Electrical work includes updates to receptacles, outlets, and related power provisions as indicated in the electrical plan. Carpet installation will be provided in designated areas, with transition strips and vinyl nosing as specified. All materials and finishes, including carpet, vinyl nosing, and pony wall braces, are based on the provided design standards. Courthouse Annex, 34 Forbes Street, Apalachicola, FL 32320 All questions requiring this project should be addressed in written form to office of the Architect by contacting Doug Shuler, AIA, (dshuler@bfbsa.com) The last day to ask questions will be February 06, 2026, at 5:00 PM, Eastern Standard Time. TIME OF SUBSTANTIAL COMPLETION The time limit for substantial completion of this work will be 180 (6 Months) calendar days from the Date of Commencement. the successful bidder will be required to enter a written contract with the Franklin County Board of County Commissioners consistent with the form contract to be provided in the Bid Documents. OWNERS RIGHT TO REJECT BIDS The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of Franklin County. All bids shall remain firm for a period of sixty days after the opening. All bidders shall comply with all applicable State and local laws concerning licensing registration and regulation of contractors doing business to the State of Florida. Franklin County encourages Minority Business Enterprises and Local Business to respond to this Bid Invitation.