Site work for a water / sewer project in Orlando, Florida. Completed plans call for site work for a water / sewer project.

Question Deadline 12/29/2025 at 5:00 PM ET Should the Contractor fail to substantially complete all Work under this Contract and make the project available for beneficial use on or before the date stipulated for Substantial Completion (or such later date as may result from extension of time granted by County), he shall pay and/or the County may retain from the compensation otherwise to be paid to the Contractor, as liquidated damages, the sum of $200.00 for each consecutive calendar day that terms of the Contract remain unfulfilled beyond date allowed by the Contract, which sum is agreed upon as a reasonable and proper measure of damages which County will sustain per diem by failure of Contractor to complete work within time as stipulated; it being recognized by County and Contractor that the injury to County which could result from a failure of Contractor to complete on schedule is uncertain and cannot be computed exactly. In no way shall costs for liquidated damages be construed as a penalty on the Contractor. For each consecutive calendar day that the work remains incomplete after the date established for Final Completion, the County will retain from the compensation otherwise to be paid to the Contractor the sum of $200.00. This amount is the mutually agreed upon minimum measure of damages the County will sustain by failure of the Contractor to complete all remedial work, correct deficient work, clean up the project and other miscellaneous tasks as required to complete all Work specified and this amount of liquidated damages is in addition to the liquidated damages prescribed above for failure to timely achieve Substantial Completion. A Bid, Payment and Performance Bond are a requirement when the offer/contract amount exceeds $100,000. Respondents shall attach an electronic copy of their bid bond for responsiveness. Submission of the bid bond, along with a certified and effectively dated copy of the power of attorney, shall be completed and signed by all required parties and submitted on the form provided in the solicitation. Submittal of a bid bond less than 10% of the total estimated contract amount for base period, shall result in the bid being deemed non-responsive. The COUNTY reserves the right to reject at its discretion any VECP submitted. Substitution of another design alternate, which is detailed in the Plans, for the one on which the Contractor bid, will not be allowed under this Section. Pending execution of a formal supplemental Agreement, implementing an approved VECP, the Contractor shall remain obligated to perform in accordance with the terms of the existing Contract.