Site work and paving for a mixed-use development in Pueblo, Colorado. Completed plans call for site work for a educational facility; sidewalk / parking lot; and for paving for a sidewalk / parking lot.

Reference Number 0000423076 Pueblo School District 60 is seeking competitive proposals for the design, engineering, purchase, delivery, and installation of concrete replacement. Question Deadline 05/13/2026 at 4:00 PM MT Response to questions due by May 15, 2026 by 4:00 p.m. Questions concerning this RFP and the procedures for responding to the RFP should be directed in writing, e-mail or fax only, to: Kassandra Naylon, Purchasing Manager Phone:719-253-6404 Fax: 719-253-6406 Pueblo School District 60 E-mail: kassandra.naylon@pueblod60.org 315 W. 11th St. Pueblo, CO 81003 Pueblo School District 60 is seeking competitive proposals for the design, engineering, demolition, purchase, delivery, for certain concrete areas at South High School. 1. Contractors will conduct a pre-bid site visit and gather information for the development of a Work Plan. As part of the Work Plan and construction activities the Contractor will identify and comply with all applicable federal, state and local statutes. The Contractor will also comply with applicable terms and conditions of the contract. 2. The finalized Work Plan and interval construction schedule will be submitted to the District's Project Manager for review and approval prior to the start of construction. The Project Manager will provide to the Contractor any existing drawings/specifications relating to the project. 3. The Contractor will mobilize construction forces necessary to begin the project within ten (10) business days after approval of the Work Plan and construction schedule by the District. 4. The Contractor will arrange for the following as needed: a. A secure staging area for storing equipment, materials, tools, and supplies, as the Contractor shall have sole liability for said items, and b. Access to and provision of utilities as needed for design and construction. 5. The following documents, plans, and reports will be provided to the Project Manager: a. Work Schedule and short interval schedule to include daily and weekly activities b. As-built drawings in electronic PDF form at the end of the project if applicable, and c. Inspection Reports as completed. 6. The Contractor will immediately notify the Project Manager of any and all issues that may result in a project delay and/or impact work quality or safety. 7. The Project Manager must be informed of and approve all work done by subcontractors; however, the District will deal only with the Contractor regarding work done and costs incurred by subcontractors. 8. All installations will be in accordance with manufacturer's recommendations. 9. The Contractor is responsible for removing all construction and packing debris from the work site and keeping a clean, safe work area at all times. Clean up of the work area shall be at no additional cost to the District. If hazardous materials are encountered during execution of the contract, the Contractor will be responsible for removing and disposing said materials in accordance with federal, state and local statutes and codes. The Contractor will provide the Project Manager with appropriate documentation regarding the disposal of said hazardous materials as requested or required. 10. Safety signs, barricades, and/or other materials will be erected by the Contractor to warn patrons and staff away from work areas. Safety of public, district staff and contractor's employees shall be a priority and shall be the responsibility of the Contractor. 11. The Contractor must notify the Project Manager in advance of work that may be disruptive to the normal school operations and parking lot traffic flow. Any shutdown of service and/or utilities must be approved and scheduled with the Project Manager. 12. The Contractor will be held liable for the cost of repair or replacement of structures, utility systems and any other parts of the project area damaged by the Contractor's acts of negligence or lack of full adherence to the requirements of the Scope contained herein. The Contractor will be held liable for the cost of repair or replacement of building components and/or vehicle(s) damaged by falling/flying equipment and/or debris. 13. Warranties for materials, labor, and equipment will be issued in accordance with industry practice. 14. Unless otherwise specified, the Contractor shall unconditionally guarantee the labor and the materials used in performance of this contract within the specified guidelines and recommendations of the manufacturer's warranty. If any defects or signs of deterioration are noted which in the District's opinion are due to faulty workmanship or materials, the Contractor shall be notified and shall make the necessary repairs to correct any deficiency in the system at the Contractor's expense. Scope Details/Specifications REMOVE AND HAUL AWAY 4 GREEN JUNIPERS AND 1 18" TREE AND REMOVE AND RESET 5 BENCHES FROM THE COURTYARD BY THE MAIN SCHOOL ENTRANCE REMOVE AND REPLACE AN 80' LONG X 75' WIDE X 4" THICK OF CONCRETE BY THE COURTYARD AT THE MAIN SCHOOL ENTRANCE REMOVE AND REPLACE A 201' LONG X 6' WIDE X 4" THICK AND A 95' LONG X 14' WIDE X 5" THICK AND A 116' LONG X 6' WIDE X 4" THICK AND A 70' LONG X 4" WIDE X 4" THICK AND A 303' LONG X 6' WIDE X 4" THICK AND 382' LONG X 6' WIDE X 4" THICK AND A 12' LONG X 8' WIDE X 4" THICK SECTIONS OF DAMAGED CONCRETE SIDEWALKS ON THE FRONT OF THE SCHOOL REMOVE AND REPLACE 3 22' LONG X 7' WIDE X 7" THICK SETS OF CONCRETE STEPS, 2 BY THE MAIN INTRANCE AND 1 BY THE NORTH PARKING LOT REMOVE AND REPLACE 150' LONG X 6' WIDE X 4" THICK SECTION OF DAMAGED CONCRETE SIDEWALK ON THE NORTH SIDE OF THE SCHOOL BY THE SCHOOL PARKING LOT.