Renovation of a museum in Oakesdale, Washington. Completed plans call for the renovation of a museum.

Oakesdale Mill Building Envelope Stabilization Project in Oakesdale, Whitman County, WA. The Port reserves the right to reject any and all bids and waive informalities. The Port of Whitman County is an Equal Opportunity and Affirmative Action Employer. Small, Minority- and WomenOwned firms are encouraged to participate in the competitive bidding process. Pursuant to Title VI of the Civil Rights Act of 1964, all respondents shall be provided a full opportunity to respond to this request and none shall be discriminated against on the ground of race, color and national origin, or sex in consideration for an award. Question Deadline 07/02/2026 at 11:00 AM PT Questions and responses will be posted in the Online Project Folder. Final Addendum: If needed, the Final Addendum will be published on 07/03/26 by 1:00 P.M. PST and will be posted in the Online Project Folder The Contractor hereby agrees to commence work under this contract promptly upon receipt of written "Notice to Proceed" from the Owner or on the date specified in the "Notice to Proceed" and to fully complete the project NO LATER THAN 120 calendar days from the date of the Notice to Proceed. If the Contractor fails to complete the work or deliver the requested material within the time specified above in this Contract, the Contractor shall pay liquidated damages at the rate of $500 per calendar day. The Architects base bid estimate range is $800,000 to $850,000. *The value for this project is based on a financial range. The value is listed as the highest possible cost from the range provided by a stakeholder or official project document. The Port of Whitman County (Port) is requesting sealed bids for 26-001-OAK, Oakesdale Mill Building Envelope Stabilization in Oakesdale, WA. The project Base Bid will consist of selective demolition, roofing, siding, and related work as noted on the plan sheet(s) and specifications. Additive alternates consist of replacement of existing windows, interior floor framing and sheathing work, and foundation improvements. All labor and materials shall be included on the bid form as specified and shall conform in strength, quality of workmanship, and material to that which is specified