Site work and paving for a road / highway in Apalachicola, Florida. Completed plans call for site work for a road / highway; and for paving for a road / highway.

As of August 13, 2021, Franklin County has not yet awarded this project because the lowest bid came in almost three times more than what the approved FEMA project worksheet had authorized as eligible costs. Franklin County is working with FEMA now to seek a project amendment to increase funding for the project. Pursuant to the regulations found at 2 Code of Federal Regulations (CFR), Part 200 at seq., in addition to the statutory authority requirements and programmatic guidance governing the Federal Emergency Management Agency (FEMA) Disaster Recovery Programs the Franklin County Board of County Commissioners will receive sealed bids from any qualified person, company or corporation interested in constructing: C30A WASHOUT REPAIR Project is located at two different sections of C30A in Franklin County, Florida and consists of regrading embankment, patching asphalt roadway due to storm damage, installing articulating concrete block, remove and replace rip-rap rubble. Completion date for this project will be 150 days from the date of the Notice to Proceed presented to the successful bidder. Liquidated damages for failure to complete the project on the specified date will be set at $250.00 per day. Please indicate on the envelope that this is a sealed bid, for "C30A Washout Repair". The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of Franklin County. All bids shall remain firm for a period of sixty days after the opening. All bidders shall comply with all applicable State and local laws concerning licensing registration and regulation of contractors doing business to the State of Florida. Franklin County encourages Minority Business Enterprises to respond to this Bid Invitation. If you have any questions, please call Erin Griffith at (850) 653-9387 Ext.158. All technical questions must be addressed in writing and emailed to Erin Griffith at erin@franklincountyflorida.com no later than June 25, 2021.