Renovation of a municipal facility in Rock Springs, Wyoming. Completed plans call for the renovation of a 30,000-square-foot, one-story above grade municipal facility.

Award Details Contract Award Date: Jun 01, 2022 Contract Award Number: 140L0622C0016 Task/Delivery Order Number: Contractor Awarded Unique Entity ID: PSQRJ6EN51K4 Contractor Awarded Name: READY SERVICES, LLC Contractor Awarded Address: Tulsa, OK 74112-5605 USA Base and All Options Value (Total Contract Value): $222117.72 ROCK SPRINGS FIELD OFFICE (RSFO) BOILER REPLACEMENT 100% SERVICE-DISABLED VETERAN OWNED SMALL BUSINESS SET-ASIDE NAICS: 238220 STANDARD SIZE: $16.50 MAGNITUDE: BETWEEN $100,000 AND $250,000 ALL WORK WILL BE IN ACCORDANCE WITH THE SCOPE OF WORK. A SITE VISIT HAS BEEN SCHEDULED FOR MARCH 1, 2022, 10:00 A.M. LOCAL MOUNTAIN TIME The work of this contract consists of: 1. Replacement of the existing heating system boiler at the Bureau of Land Management (BLM) Rock Springs District Office, including demolition of the existing heating system boiler and boiler pump; installation of new boilers and boiler pumps; blanking off the existing combustion air louver; and reconfiguring and reprogramming the existing HVAC control system to accomplish the proposed HVAC control sequence of operation. Period of Performance: 04/01/2022 to 10/31/2022 Magnitude: BETWEEN $100,000 AND $250,000 NAICS: 238220 SIZE STD: $16.50 SET-ASIDE: SERVICEDISABLED VETERAN-OWNED SMALL BUSINESS Proposal Submittal Information: Site Visit: MARCH 1, 2022, 10:00 A.M. Local Mountain Time Questions Due Date: MARCH 4, 2022, 11:00 A.M. Local Mountain Time Proposal Due Date: MARCH 15, 2022, 1:00 P.M. Local Mountain Time The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 213 calendar days after receipt of the notice to proceed. The time stated for completion shall include final cleanup of the premises. H-1 WORK HOURS The performance period established for this contract is based upon all work being conducted during regular working hours between 7:30am and 5:30pm, Monday through Friday, excluding government holidays. If the Contractor desires to carry on work outside regular hours, including Saturdays, Sundays, and government holidays, a request must be submitted to the Contracting Officer in sufficient time to allow satisfactory arrangements to be made by the Government for access to the work site and inspection. H-2 FIRE DANGER SEASON If the Contracting Officer Representative (COR) allows the Contractor to continue work during periods of declared fire danger or season, the Contractor shall comply with all applicable state laws relating to fire prevention and with all special conditions of work as directed by the COR. H-3 DRAWINGS (a) Typical Drawings. Any drawings titled typical are general only and dimensions of each structure will be fixed by the Contracting Officer to adapt the design to existing conditions at the structure location. (b) Reduced Size Drawings. Any drawings identified as "REDUCED SIZE DRAWINGS" appearing in the solicitation are photographically reduced in size. Accordingly, measurements and dimensions should not be taken or be based on any numerical scales shown. Prospective bidders desiring to review a copy of the full-size drawings may contact the Contracting Officer identified in the solicitation. H-4 PRESERVATION OF HISTORICAL AND ARCHEOLOGICAL DATA (a) The Historic and Archeological Data Preservation Act of 1974, provides for the preservation of historical and archeological data that might otherwise be lost as the result of alterations to the terrain caused by a federal or federally licensed activity or program. (b) If, in connection with operations under this contract, the Contractor, subcontractors, or the employees of any of them, discovers, encounters or becomes aware of any possible historical or archeological data, objects or sites of cultural value on the project area, such as historical ruins, graves or grave markers, fossils, or artifacts, the Contractor shall immediately suspend all operations in the vicinity of the cultural value and shall notify the Contracting Officer in writing, giving the location and nature of the findings. No objects of cultural resource value may be removed. (c) Where appropriate by reason of discovery, the Contracting Officer may order delays in the time of performance and/or changes in the work. If such delays and/or changes are ordered, the time of performance and contract price shall be adjusted in accordance with the Changes clause. (d) The Contractor will be responsible for protecting the cultural resources within the affected area from damage. In addition, the contractor will be liable for all damage to the identified cultural resources caused by their actions or the actions of their agents or representatives. The Contractor shall immediately notify the Contracting Officer or his representative if any damage occurs to any cultural resource and immediately suspend work in the area in which damage has occurred until authorized to proceed. SAFETY AND QUALITY CONTROL PLAN Within 10 days following contract award, the contractor must provide effective quality control/assurance and safety plans for acceptance by the Government. ) If the decision of the Administrator is not favorable, an interested party may appeal directly to the Administrative Review Board (formerly the Wage Appeals Board). Write to: Administrative Review Board U.S. Department of Labor 200 Constitution Avenue, N.W. Washington, DC 20210 4.) All decisions by the Administrative Review Board are final.