Site work and new construction of a civil project in Cape San Blas, Florida. Completed plans call for the construction of a water / sewer project; and for site work for a water / sewer project.

This project includes construction of a water booster station on Cape San Blas. The station will be installed in line with the existing 8 PVC water main and will consist of a triplex (20 Horsepower each) pump skid designed to automatically boost pressure between the water supply plants called LUCI I and II and the storage and pumping facility known as LUCI III. The skid and electrical components will be housed in a 14 X 20 feet building adjacent to S.R. 30-E (Cape San Blas Road). The project also includes cleaning and painting the hydropnueumatic tank at the LUCI II plant and the following improvements at the LUCI III plant: new generator and automatic transfer switch with electrical upgrades, replacing the ground storage tank roof, finished water flow meter, and general building repairs and painting. Completion date for this project will be 300 days from the date of the Notice to Proceed presented to the successful bidder. Liquidated damages for failure to complete the project on the specified date will be set at $500.00 per day. All bids shall remain firm for a period of sixty days after the opening. All bidders shall comply with all applicable State and local laws concerning licensing registration and regulation of contractors doing business to the State of Florida. The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of Gulf County. Project No. M121-106-111