This is a service / maintenance or supply contract in Marina, California. Contact the soliciting agency for additional information.

The goal for this project is for the abatement, proper removal, and disposal of 45 barracks buildings and miscellaneous debris at the proposed City Park located along Second and 8th Street and 30 buildings and miscellaneous debris at the Cypress Knolls area along Rendova and Third Avenue for future park and or residential development. The work in general is not limited to; installation and maintenance of BMPs from Storm Water Pollution Prevention Plan, tree protection and protective fencing. Tree removal and trimming as shown on the plans and further described on the Specifications and Tree Removal Permit and Arborist Report, Attachments 3. Abatement, and proper disposal of all hazardous materials on the sites described on the attached Pre demolition Hazardous Material Inspection Reports, Attachments 1 and 2 and removal of buildings on the two sites shown on the plans. Also included are utilities capping and repair and removal and disposal of roadways, walkways and retaining walls, rough grading, and site restoration. The Contractor shall perform all work necessary to complete the City Park Barracks and Cypress Knolls Buildings Blight Removal project in their entirety in accordance with the Contract Documents. Time for Completion - All work under this contract (Base Bid plus Additive Alternative) shall be completed before the expiration one hundred fifty (150) working days from the date specified in the Notice to Proceed. One hundred twenty-five (125) working days for Base Bid Twenty-five (25) working days for Additive Alternative Bids. If Contractor shall be delayed in the work by the acts or neglect of Owner, or its employees or those under it by contract or otherwise, or by changes ordered in the work, or by strikes, lockouts by others, fire, unusual delay in transportation, unavoidable casualties or any causes beyond the Contractor's control, or by delay authorized by the Owner, or by any cause which the Owner shall decide to justify the delay, then the time of completion shall be extended for such reasonable time as the Owner may decide. Liquidated damages amount per working day shall be as specified in the Special Provisions. All Federal holidays and City holidays observed during construction shall not be included on the construction timeline specified. Time extension for weather and City delays will be granted accordingly. All contractors submitting bids must have a valid as of the date of bid opening a California Class "A" or "B" contractor's license. Hazardous material abatement shall be completed by a licensed C-22 contractor or BCP Section 7058 asbestos certified and DOSH registered. Building demolition shall be completed by C21 licensed contractor as required on this contract Bid results and inquiries may be obtained from the City of Marina at (831) 884-1212 or email Elvie Camacho at elviec@wallacegroup.us. Responses to all inquiries shall be sent out through email or if necessary, bids will be available for inspection by appointment only. This Contract will be subject to compliance monitoring and enforcement by the California Department of Industrial Relations, pursuant to Labor Code section 1771.4. Under California Labor Code section 1771. 1, as amended by SB 854, a contractor may not bid, nor be listed as a subcontractor, for any bid proposal submitted for a public work unless the contractor and its subcontractors are registered and qualified to perform public work pursuant to section 1725.5 of the Labor Code. The Bidder and its Subcontractors must be registered and qualified to perform public work pursuant to section 1725.5 of the Labor Code, subject to limited legal exceptions under Labor Code section 1771. 1. Attention of bidders is called to the fact that effective January 1, 1977, the Director of the State Department of Industrial Relations is required to determine the general prevailing rate of minimum wages to be paid to the various craftsmen and laborers required to construct said improvements. The City Council is cognizant of the prevailing rate of per diem rates and the general prevailing rate for holiday and overtime work in the locality in which the public work is to be performed for each craft, classification or type of workman needed to execute this contract and has made this information a part of the Specifications and Contract for said work by reference thereto. Pursuant to the provisions of the California Public Contract Code Section 20103.8, City reserves the option to award any or all the additive bid items in addition to the original contract after the lowest responsive responsible Bidder has been determined, should the City later obtain additional funding for additive alternatives not awarded with the original contract. The City Council reserves the right to reject any or all bids and to determine which proposal is, in its judgement, the most responsive bid of a responsible bidder and which proposal should be accepted in the best interest of the City. The City Council also reserves the right to waive any informality in any proposal or bid. Proposals received after the time announced for the opening will not be considered. No bidder may withdraw his bid after the time announced for the opening, or before the aware and execution of the contract, unless the award is delayed for a period exceeding ninety (90) days. No telegraphic proposals will be accepted. Contract award will be made to the lowest responsive and responsible bidder based on Base Bid plus Additive Alternate Bids 1 and 2.