Site work and paving for a mixed-use development in Sacramento, California. Completed plans call for site work for a road / highway; for paving for a road / highway; sidewalk / parking lot; and sidewalk / parking lot.

Question Submission Deadline:May 6, 2022, 4:00pm PRE-BID QUESTIONS DUE VIA Q&A: Date: Friday, May 6, 2022 No later than: 4:00 pm The work to be performed under this contract includes the furnishing of all labor, materials, equipment, and and other incidental work for: Construction of a new concrete top layer upon the existing floor of the waste tipping building. The work to be performed in general includes grinding the existing concrete surface as needed and indicated on the plans, preparing the existing surface for placement of new flooring surface, installation of concrete, finishing new surface with sufficient roughness for proper traction.CONTRACTOR LICENSE REQUIRED: C-8 The successful bidder shall be required to execute a material and labor Payment Bond and Performance Bond, issued by a corporate surety, acceptable to the County of Sacramento, each for not less than one hundred percent (100%) of the contract price. Each bid must be submitted on the bid forms provided in the Contract Documents; however, if none are provided, the surety may issue on its own paper. Each bid must also be accompanied by security in the form of a bid bond issued by a corporate surety, a certified check or cashier's check payable to the Treasurer of Sacramento County, or cash for an amount not less than ten percent (10%) of the aggregate sum of the bid. Direct pre-bid questions to the Project Manager, Peter Hoseit, via the Q&A tab in the portal. ALL PRE-BID QUESTIONS MUST BE SUBMITTED IN WRITING NO LATER THAN Friday, May 6, 2022 BY 4:00 pm. Questions received after that time will not be answered. Responses will be by addenda to the bid documents. The Board reserves the right to reject any or all bids, to waive any informality in any bid, and to determine which bid, in their judgment, is the lowest responsive bid of a responsible Bidder. Liquidated damages shall be $1,000.00 for each calendar day(s) delay beyond the established contract completion date that all work, is not completed.