Site work and paving for a sidewalk / parking lot in Aledo, Illinois. Completed plans call for site work for a sidewalk / parking lot; and sidewalk / parking lot.

The City of Aledo is soliciting proposals from qualified firms for the replacement of existing concrete on the north side of the Police Department / Public Works building located at 200 N.E. 2nd Street in Aledo, Illinois The City of Aledo is seeking proposals from qualified firms to provide the following services: Removal of Existing Concrete. The Respondent must demolish, remove and properly dispose of all existing concrete. The area involved is approximately 2,575 square feet--approximately thirty-three feet (33') by seventy-eight feet (78'). New Concrete Installation. The Respondent must install a new concrete approach and drive. Concrete shall be installed upon a base of not less than four inches (4") of appropriate gravel. The concrete shall be not less than six inches (6") thick with iron reinforcement bars and appropriate expansion joints. All saw-cut joints shall be caulked and sealed. Completion Date. All work on the project must be completed not later than October 14, 2022. The City reserves the right to negotiate pricing and terms after the proposals have been received. The City further reserves the right to re-issue this RFP with modifications if a suitable vendor is not found. The City of Aledo reserves the right to reject any or all proposals, waive minor informalities, and to award the contract(s) to one or more Respondents based upon what the City believes is in the best interests of the citizens of the City. Nothing in this RFP shall require that the City take the lowest price proposal. Instead, the City reserves the right to base the decision on the entirety of the information provided, criteria requested, and the sole judgment of City officials. Questions. All questions regarding this RFP should be in writing and directed to: Jarod Dale, Aledo City Clerk or Chris Sullivan, City Administrator 120 North College Avenue, Aledo, IL 61231 cityclerk@aledoil.gov / csullivan@aledoil.gov City Clerk Jarod Dale and City Administrator Chris Sullivan are the only city representatives who are authorized to provide information on the bid procedures and the Project.