Site work and paving for a road / highway in Port St Joe, Florida. Completed plans call for site work for a road / highway; and for paving for a road / highway.

The City of Port St. Joe will receive sealed bids from any qualified person, company or corporation interested in constructing: Avenue C, D, and Williams Avenue Parking Resurfacing This project consists of milling and resurfacing approximately 0.29 miles of Avenue C & D from Martin Luther King Blvd. to Peters Street, along with paving Williams Avenue parking in Port St. Joe, Florida. The completion date for this project will be 90 days for Substantial Completion and 120 days for Final Completion from the date of the Notice to Proceed presented to the successful bidder. Liquidated damages for failure to complete the project on the specified date will be set at $500.00 per day. Please indicate on the envelope that this is a sealed bid, for the "AVE. C, D, and WILLIAMS AVE. PARKING RESURFACING". Questions regarding the project must be submitted in writing by,to Josh Stephens at jstephens@dewberry.com prior to October 14, 2022. All bidders shall comply with all applicable State and local laws concerning licensing registration and regulation of contractors doing business to the State of Florida. If you have any questions, please contact Josh Stephens at (850) 571-1218 or e-mail at jstephens@dewberry.com. The City of Port St. Joe reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in their best interest. All bids shall remain firm for a period of sixty days after the opening.