Renovation of a mixed-use development in San Juan, Puerto Rico. Completed plans call for the renovation of a medical facility.

2. All references to "Bid" or "Bidder" shall be understood to mean "Offer" or "Offeror". 3. MAGNITUDE OF THIS PROJECT: Between $2,000,000 and $5,000,000 in accordance with (IAW) VAAR 836.204(f)(2). 4. PROPOSAL DUE DATE: Standard Form (SF) 1442, block 13a (or as amended on SF 30), refers to proposals due date. 5. SITE VISIT: An organized site visit has been scheduled. Refer to FAR 52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995) Alternate I (FEB 1995) for location, date, and time details. 6. OFFER ACCEPTANCE PERIOD: Offers providing less than one-hundred and twenty (120) calendar days for Government acceptance after the date offers are due will not be considered and will be rejected. 7. REQUESTS FOR INFORMATION/QUESTIONS: Requests for Information (RFIs) or questions shall be submitted via email to ana.alvarado@va.gov by the Prime Offeror SDVOSB. Prime offeror should consolidate RFIs/questions from its team members and submit as one submission to the maximum extent practicable. 7.1. Offerors may submit RFIs or questions via email to ana.alvarado@va.gov at any time; however, RFIs or questions received after February 17, 2023 @ 1:00 PM (AST) may not be answered. 7.2. To easily identify all RFIs or questions for this project, email subject line shall be titled using the following format: RFI - SOLICITATION NUMBER - OFFEROR COMPANY NAME. 7.3. No telephone RFIs/Questions will be accepted. 8. SPECIFICATIONS AND DRAWINGS: All applicable specifications and drawings will be provided electronically along with the solicitation. No hard copies will be made available to offerors. 9. Any reference contained within contract specifications and/or drawings to the "VA Engineer", "Resident Engineer", "Senior Resident Engineer", "Project Manager", Contracting Officer Technical Representative, or their abbreviations are to be replaced with "Contracting Officer Representative (COR)" 10. SERVICE-DISABLED Veteran-owned Small Business Verification: This solicitation is 100% set asides for verified Service-Disabled Veteran-Owned Small Businesses (SDVOSBs). The award of this requirement shall not be delayed due to loss of SDVOSB verification. Proposals submitted by non-verified SDVOSBs shall be excluded from award consideration. SITE VISIT (CONSTRUCTION) (FEB 1995) ALTERNATE I (FEB 1995) (a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed. (b) An organized site visit has been scheduled for-- February 10, 2023 @ 10:30AM (AST) (c) Participants will meet at-- VA Main Bldg. Basement, Office B13 Project Section. *The value for this project is based on a financial range. The value is listed as the highest possible cost from the range provided by a stakeholder or official project document. LIQUIDATED DAMAGES A. Liquidated damages shall be applied after the end of the performance period at a rate of $1,500.00 daily unless the project has been accepted by the Government as substantially completed or a time extension was granted to the Contractor.