Site work and paving for a road / highway in Dayton, Ohio. Completed plans call for site work for a road / highway; and for paving for a road / highway.

As of August 7, 2023, this project has not yet been awarded. A timeline for award has not yet been established. The City reserves the right to reject any and all proposals, to waive any irregularities in a proposal, or to accept the proposal(s) which in the judgment of proper officials, is in the best interest of the City. The City reserves the right to accept a part or parts of a proposal unless otherwise restricted in the RFP or issue subsequent RFP Neither the City nor Contractor shall be considered in default of this Agreement for delays in performance caused by circumstances beyond the reasonable control of the non-performing party. For purposes of this Agreement, such circumstances include, but are not limited to, abnormal weather conditions; floods; earthquakes; fire; epidemics; war, riots, and other civil disturbances; strikes, lockouts, work slowdowns, and other labor disturbances; sabotage; judicial restraint; and inability to procure permits, licenses, or authorizations from any local, state, or federal agency for any of the supplies, materials, accesses, or services required to be provided by either the City or Contractor under this Agreement, provided the aforementioned circumstances are not due to the negligence or fault of the asserting party or any of its agents, employees, contractors, sub-contractors and/or representatives A Project Mobilization Meeting will be held to introduce each other and to clarify any questions relating to project scope. A Project Mobilization Meeting will outline contact persons and communication protocol. At this meeting, all issues related to the specific job and its division of responsibilities will be resolved. The Consultant will be provided with a complete set of right-of-way plans and legal descriptions for all effected properties at the meeting or as the plans and descriptions become available. Question Deadline 06/05/2023 at 5:00 PM ET 10% MBE Participation Goal