Renovation of a playground / park / athletic field in Wewahitchka, Florida. Completed plans call for the renovation of a 77,433-square-foot playground / park / athletic field.

All technical questions must be addressed in writing and emailed to Caleb Brown at cbrown@dewberry.com no later than August 23rd , 2023. The Franklin County Board of County Commissioners will receive sealed bids from any qualified person, company or corporation interested in constructing: VROOMAN PARK BALLFIELD IMPROVEMENTS Project is located in Franklin County, Florida and consists of the reconstruction of two (2) baseball/softball fields in Vrooman Park located on the northeast side of the intersection of 6 th St and Avenue A in Eastpoint, FL. Completion date for this project will be 90 days from the date of the Notice to Proceed presented to the successful bidder. Liquidated damages for failure to complete the project on the specified date will be set at $750.00 per day. Please indicate on the envelope that this is a sealed bid, for VROOMAN PARK BALLFIELD IMPROVEMENTS . The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of Franklin County. All bids shall remain firm for a period of sixty days after the opening. All bidders shall comply with all applicable State and local laws concerning licensing registration and regulation of contractors doing business to the State of Florida. All technical questions must be addressed in writing and emailed to Caleb Brown at cbrown@dewberry.com no later than August 23 rd , 2023.