Renovation of a mixed-use development in Bessemer, Alabama. Completed plans call for the renovation of a educational facility.

Plans and specifications are for viewing purposes only. Official sets must be obtained from McKee and Associates. The project shall be bid excluding taxes. Bids must be submitted on proposal forms furnished by the Architect or copies thereof. No bid may be withdrawn after scheduled closing for receipt of bids for a period of ninety (90) days. Bids must be submitted on proposal forms furnished by the Architect or copies thereof. The Owner reserves the right to reject any or all proposals and to waive technical errors if, in the Owners judgment, the best interests of the Owner will thereby be promoted. A certified check or Bid Bond payable to Bessemer City Schools in an amount not less than five percent (5%) of the amount of the bid, but in no event more than $10,000.00 must accompany the bidder's sealed proposal. Performance and statutory labor and material payment bonds will be required at the signing of the Contract. Completion Time: See Scope of Work in Project Manuals The Owner reserves the right to reject any or all proposals and to waive technical errors if, in the Owners judgment, the best interests of the Owner will thereby be promoted. LIQUIDATED DAMAGES for which the Contractor and its Surety (if any) shall be liable and may be required to pay the Owner in accordance with the Contract Documents shall be equal to six percent interest per annum on the total Contract Sum unless a dollar amount is stipulated in the following space, in which case liquidated damages shall be determined All General Contractors bidding on this project shall be required to visit the site and examine all existing conditions prior to submitting their proposal. All Bidders shall have general liability and work manís compensation insurance. All RFIs and RFAs regarding the bid documents shall be sent and addressed through emails found on the RFI and RFA forms in the project manual. Note: Only The RFI And RFA Forms In The Project Manual Will Be Accepted. The Architect will not accept inquiries via telephone or fax. Document note: Pdfs Of The Project Can Be Reviewed By Going To online. The documents may be viewed on-line and printed by General Contractors, Sub-Contractors and Suppliers. Documents published through this procedure are the only documents endorsed by the Architect. The Architect retains ownership and copyrights of the documents. If bidders require printed sets, please submit request to the Architect at mckeeplans@gmail.com. Include your first & last name, company name, address, phone number and the project name and number. Print sets are to be returned, in reusable condition, within ten days after bid opening. PN - 24.132