Renovation of an educational facility in Bessemer, Alabama. Completed plans call for the renovation of a educational facility.

Plans and specifications are for viewing purposes only. Official sets must be obtained from McKee and Associates. The project shall be bid excluding taxes. Bids must be submitted on proposal forms furnished by the Architect or copies thereof. No bid may be withdrawn after schedule closing for receipt of bids for a period of ninety (90) days. Bids must be submitted on proposal forms furnished by the Architect or copies thereof. The Owner reserves the right to reject any or all proposals and to waive technical errors if, in the Owners judgment, the best interests of the Owner will thereby be promoted. A certified check or Bid Bond payable to Bessemer City Schools in an amount not less than five percent (5%) of the amount of the bid, but in no event more than $10,000.00 must accompany the bidder's sealed proposal. Performance and statutory labor and material payment bonds will be required at the signing of the Contract. If no other bids are received, the full amount of the bid guaranty shall be so retained or recovered as liquidated damages for such default. Any sums so retained or recovered shall be the property of the Awarding Authority. The submission of a bid shall constitute a representation by the bidder that the bidder has made such examination and visit and has judged for and satisfied himself or herself as to conditions to be encountered regarding the character, difficulties, quality, and quantities of work to be performed and the material and equipment to be furnished, and as to the contract requirements involved. All General Contractors bidding on this project shall be required to visit the site and examine all existing conditions prior to submitting their proposal. All Bidders shall have general liability and workmanís compensation insurance. Completion Time: See Scope of Work in Project Manuals . Supervision: Contractor to ensure proper supervision of all work. Document note: Pdfs Of The Project Can Be Reviewed By Going To online. The documents may be viewed on-line and printed by General Contractors, Sub-Contractors and Suppliers. Documents published through this procedure are the only documents endorsed by the Architect. The Architect retains ownership and copyrights of the documents. If bidders require printed sets, please submit request to the Architect at mckeeplans@gmail.com. Include your first & last name, company name, address, phone number and the project name and number. Print sets are to be returned, in reusable condition, within ten days after bid opening.