Renovation of a mixed-use development in Greensboro, Alabama. Completed plans call for the renovation of a educational facility.

The Scope of the Work of the Contract is meant to be viewed as a successor to the General Special Conditions of the Contract. Should any discrepancy or ambiguity be noted, the Scope of the Work of the Contract shall apply and the General Special Conditions of the Contract shall defer to Scope of the Work of the Contract Documents. The scope of the work shall be taken in its entirety by all contractors. In signing the contract all contractors have read and understand that the Scope of the Work and the General Special Conditions are taken in their entirety. The Owner reserves the right to reject any or all proposals and to waive technical errors if, in the Owners judgment, the best interests of the Owner will thereby be promoted. All bidders bidding in amounts exceeding that established by the State Licensing Board for General Contractors must be licensed under the provisions of Title 34, Chapter 8, Code of Alabama, 1975, and must show evidence of license before bidding or bid will not be received or considered by the Architect. All bidders shall show such evidence by clearly displaying their current license number on the outside of the sealed envelope in which the proposal is delivered. When the amount bid for a contract exceeds $50,000, the bidder must be licensed by the State Licensing Board for General Contractors and must show the Architect evidence of license before bidding or the bid will not be received by the Architect or considered by the Awarding Authority. A bid exceeding the bid limit stipulated in the bidder's license, or which is for work outside of the type or types of work stipulated in the bidder's license, will not be considered. In case of a joint venture of two or more contractors, the amount of the bid shall be within the maximum bid limitation as set by the State Licensing Board for General Contractors of the combined limitations of the partners to the joint venture. If no other bids are received, the full amount of the bid guaranty shall be so retained or recovered as liquidated damages for such default. Any sums so retained or recovered shall be the property of the Awarding Authority. A certified check or Bid Bond payable to Hale County Board of Education in an amount not less than five percent (5%) of the amount of the bid, but in no event more than $10,000.00 must accompany the bidder's sealed proposal. Performance and statutory labor and material payment bonds will be required at the signing of the Contract.