Renovation of a playground / park / athletic field in Blasdell, New York. Completed plans call for the renovation of a playground / park / athletic field.

Removal and installation of new fixtures, partitions, interior painting and other work indicated in the Contract Documents. D006262 $12,430.00 Twelve thousand four hundred and thirty dollars and zero cents The Estimate Range for this project is: $221,875.50- $300,184.50. Minority Owned Business Enterprise (MBE) 4% Women Owned Business Enterprise (WBE) 14% Service-Disabled Veteran Owned Business 10% PROJECT COMPLETION The completion date for this project is 250 Days after agreement has been approved by the NYS Comptroller's Office. Project Specific Liquidated Damages (Refer to Article 14.10 of the General Conditions). $1,000/ Day. Each bid must be prepared and submitted in accordance with the Instructions to Bidders and must be accompanied by a scanned Bid Security in the form of a certified check, bank check, or bid bond in the amount of: $12,430.00. WITHDRAWAL OF BID A bid may be withdrawn at any time prior to the time specified for opening. After the bid opening, a bidder may request the withdrawal of its bid by a written application on the grounds of a demonstrable mistake. Such written application must be made within seven days after the bid opening unless the Office, at its sole discretion, grants a time extension. Upon receiving such written application, the Office will review and decide the bidder's withdrawal request based on the three elements below. A bid may be withdrawn if, before any detrimental change of position by the State has occurred, the bidder establishes that: 1. a verifiable error occurred in the computation of the bid, and 2. absent the mistake the bid would have been substantially higher, and 3. if directed to proceed with the Contract at the price set forth in the bid, the bidder would suffer a substantial loss on the contract. Each element must be proven by clear and convincing evidence in order to justify withdrawal. The judgment of the Office shall be final and conclusive. Should the judgment be against allowing withdrawal, then the failure of the bidder to proceed would be cause for forfeiture of its bid bond. The successful bidder will be required to furnish a Performance Bond and a Labor and Material Bond/Payment Bond in the statutory form of public bonds required by Sections 136 and 137 of the State Finance Law, each for 100% of the amount of the Contract. *The value for this project is based on a financial range. The value is listed as the highest possible cost from the range provided by a stakeholder or official project document.