Site work and paving for a road / highway in Port St Joe, Florida. Completed plans call for site work for a road / highway; and for paving for a road / highway.

**As of September 17, 2024, the award amount is $305,671.90. Monument Avenue Resurfacing. This project consists of resurfacing approximately 0.312 miles of Monument Avenue from the 19th Street bridge to Allen Memorial Way in Port St. Joe, Florida. The project also involves stripping and other safety improvements. All bidders shall be FDOT Qualified per Section 2-1 of the FDOT Standard Specifications for Road and Bridge Construction, latest edition in the following work classes: Grading, Drainage, Flexible Paving, and Hot Plant Mix-Bituminous Course. The completion date for this project will be 60 days for Substantial Completion and 90 days for Final Completion from the date of the Notice to Proceed presented to the successful bidder. Liquidated damages for failure to complete the project on the specified date will be set at $500.00 per day. Please indicate on the envelope that this is a sealed bid, for the Monument Avenue Resurfacing . The City of Port St. Joe is an Equal Opportunity / Affirmative Action, Drug-Free Work Place Employer / Handicapped Accessible / Fair Housing Jurisdiction. Estimated budget is $349,936.95. The City of Port St. Joe reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in their best interest. All bids shall remain firm for a period of sixty days after the opening. Questions regarding the project must be submitted in writing to Josh Stephens at jstephens@dewberry.com prior to August 23, 2024. All bidders shall comply with all applicable State and local laws concerning licensing registration and regulation of contractors doing business to the State of Florida.