Site work and paving for a road / highway in Kingsland, Georgia. Completed plans call for site work for a road / highway; and for paving for a road / highway.

The City of Kingsland is seeking proposals for the 2025 LMIG Asphalt Resurfacing Project. City of Kingsland Public Works Department is seeking vendors to construct Asphalt Resurfacing on City roads/streets. Work is to include tack, striping and traffic control. City of Kingsland will provide all manhole and valve extension rings to be installed by the contractor at time of paving. Striping to match existing layout including R/R crossings, stop bars, crosswalks and long lines unless noted otherwise. All striping is to be completed using thermoplastic with reflective beads. Overlay to be 1.5 inches of .95 asphalt. Work shall be completed no later than 180 Days following the commencement date of the contract and following written "Notice to Proceed" by Owner. The Contract time may be extended as approved by the City of Kingsland in an amount equal to time lost due to delays beyond the control of Contractor. Such delays shall include, but not be limited to, acts or neglect by Owner or others performing additional work, fires, floods, abnormal weather conditions or acts of God. VENDOR and OWNER recognize that time is of the essence of this Agreement and that OWNER may suffer financial loss or liability if the Work is not completed within the times specified; plus, any extensions thereof allowed by an official written request and approval of an extension of time. The parties also recognize the delays, expense, and difficulties involved in proving, in a legal or arbitration proceeding, of the actual loss suffered by OWNER if the Work is not completed on time. Accordingly, instead of requiring any such proof, OWNER and VENDOR agree that as liquidated damages for delay (but not as a penalty), VENDOR shall pay OWNER $300.00 for each calendar day that expires after the time specified for completion until the work or product is finalized and accepted by the City. Any questions shall be directed as follows: Scope of Work Technical Questions Ron Knox, Assistant Public Works Director PH: (912) 729-8236 Email: rknox@kingslandgeorgia.com Request for Proposal Questions or Submittals Hannah Smith, Purchasing Agent PH: (912) 729-8113 hsmith@kingslandgeorgia.com 10% Bid Bond Provide a statement proposal is valid for a period of not less than 90 calendar days from date of receipt.