Renovation of a fitness / recreation center in Belmond, Iowa. Completed plans call for the renovation of a fitness / recreation center.

The work for the project shall be accomplished under a Single Construction Contract and there will be a Single Bid to include all of the following: 1. General Construction. 2. Mechanical Construction, including: Plumbing, Heating, Ventilating, andAir Conditioning. 3. Electrical Construction, including: Power, Lighting, Communication, and Fire Safety. PROJECT AND LOCATION Iowa Specialty Hospitals & Clinics Fitness Center Renovation 403 1st Street SE Belmond, IA 50421 Each Bid shall be accompanied by Bid Security, in a separate sealed envelope, in the form of either (1) cash, cashiers check or certified check or certified share draft drawingonacredit union in Iowa or chartered under the laws of the United States, in an amount equal to at least Five (5%) Percent of Project Bid Amount or (2) a Bid Bond executed by a corporationauthorizedto contract as a surety in the State of Iowa with the amount or penal sumof not lessthanFive(5%) Percent of Project Bid Amount. The bid security should be made payabletoIowaSpecialty Hospitals & Clinics. Such bid security shall be forfeited to Iowa Specialty Hospitals& Clinics as liquidated damages in the event the successful bidder fails or refusestoenter intoaContract within ten (10) days after the Award of Contract and post bond satisfactory to said owner insuring the faithful fulfillment of the Contract pursuant to the provisions of thisNoticeandthe other Contract Documents. No bidder may withdraw their bid for at least forty-five (45) days after the scheduledclosingtimefor the receipt of bids. The Board of Directors of Iowa Specialty Hospitals & Clinics of Belmond, IA, reserves the right to reject any or all bids and waive all informality and irregularity in connectiontherewithif the same is judged to be in their best interests, and to make a selection, including that of any Alternate Bids, that in their judgment is best suited for the purpose intended for theproject On Thursday, December 19, 2024, the Board of Directors of the Belmond Clinic, 4031st StreetSE, Belmond, IA will review the Bids and consider the Award of the Contract. On-site mobilization and construction may begin immediately upon executionof theOwner-Contractor Agreement and acceptable submittal of the Performance Bond, Labor andMaterial Bond, and Certificate of Insurance. The Owner requires substantial completion for the project by Friday, March 14, 2025. All bids shall be on the basis of cash payment for the work. The Owner reserves the right to reject any or all bids and waive all informalities and irregularities in connection therewith if the same is judged to be in their best interests, and to make a selection, including that of any Alternate Bids, that in their judgment is best suited for the purpose intended for the project. Doc Notes: These Documents may be obtained after the afore mentioned date by Prime Contractors upon request to the Architect and on the condition they be returned after the receipt of bids. There will be no Contract Document deposit.