Site work for a water / sewer project in Miami, Florida. Completed plans call for site work for a water / sewer project.

License Requirements - At the time of Bid and pursuant to the requirements of Section 10-3 of the Code of Miami-Dade County, Florida and Request for Price Quotation (RPQ) and Contract Documents, the Bidder and all its subcontractor must hold a valid, current, and active State and/or Miami-Dade County contractor's license consistent with the requirements of the Scope of Work. Water and Sewer - William Diaz - Telephone No.: (786) 552-8216 RPQ No. P20062 - SALTFRONT MONITORING WELLS INSTALLATION ESTIMATED COST: $910,425.00 LICENSE REQUIREMENT: Water Well Contractor SCOPE OF WORK: The purpose of this project is the Installation (drilling) of fourteen (14) Salt-Front Monitoring Wells (MWs) at different proposed locations along the east portion of Miami Dade County. Seawater encroachment continues to represent a major threat to the freshwater resources of coastal Miami-Dade County. The installation of these 14 wells will help to further delineate the extent of saltwater intrusion in areas where the saltwater front is currently estimated, to better define the saltwater front in areas where existing monitoring wells are already on the saltwater side of the front, and to better understand the hydrology of the Biscayne aquifer along the salt front. The objective of this project is to drill 14 salt front monitoring wells (SF 22-1 through SF 22-14), that can be drilled with a conventional drill bit but they must fully penetrate the Biscayne aquifer and have a stable and clean borehole for geophysical data collection. Sonic drilling will not be allowed in this project. Each well will be screened at the bottom of the deepest transmissive layer within the Biscayne aquifer, and additional sample tubes and filter packs may need to be installed in shallower flow zones, depending on the results of the geophysical logs. Due to unforeseen permitting time delays, the installation of the 14 wells may be delayed accordingly. Note: A Bid Bond will be required only if the bid meets or exceeds $200K. In addition, a Performance and Payment Bond with additional insurance will be required once bid is Awarded and bid meets or exceeds $200K. The bid set includes electronic bid instructions. Training on electronic bid submission is available every Monday from 9-10 and every Wednesday from 1 - 2. Email the Contracting Officer or paul.adams@miamidade.gov for further information or to schedule training on alternative dates. REQUEST FOR INFORMATION (RFI):The RFI cut-off date is five (5) business days prior to the bid due date. Question Deadline 01/07/2025 Liquidated Damages - $1,000.00 per day.