Site work for a water / sewer project in Gainesboro, Tennessee. Completed plans call for site work for a water / sewer project.

The work shall be paid for using ARP Grant funds. The work is to be bid in One (1) Contract and consists of the following approximate quantities together with all necessary appurtenances CONTRACT 4(Jackson County Portion)The work to be performed under this Contract is itemized under this schedule of construction of approximate quantities listed as follows:(1) Shelleys TankThis project involves the interior and exterior renovations and sanitary repairs to the following existing waterstorage tank(s) for Jackson County Utility District, TN: 100KG Standpipe, Shelleys Tank, located at 177 Cal DavidLane, Gainesboro, TN 38562(2) Ben Hill TankThis project involves the interior and exterior renovations and sanitary repairs to the following existing water storage tank(s) for Jackson County Utility District, TN: 75KG Standpipe, Ben Hill Tank, located at 550 N. GrundyQuarles Hwy, Gainesboro, TN 38562 and other appurtenant work as shown on the Plans and described in the Specifications and at locations to be identified by the Jackson County Utility District. Bid shall be submitted on the separate copy of the PROPOSAL supplied for that purpose. All bidders must be licensed general contractors as required by the Contractor's Licensing Act of 1976 of theGeneral Assembly of the State of Tennessee, and qualified for the type of construction being bid upon. Each bidder shall write on the outside of the envelope containing his bid (1) his contractor's license number, (2) the license expiration date, and (3) that part of the classification applying to the bid. If this is not done, the bid will not be opened. Bids shall be accompanied by a certified check or bid bond in an amount equal to five percent (5%) of the bid to insure the execution of the Contract for which such bid is made. In case the bid is not accepted, the check or bid bond will be returned to the bidder, but if the bid is accepted and the bidder shall refuse or neglect to enter into a Contract with Jackson County, Tennessee, within ten (10) days from the time he shall be notified of the acceptance of his bid, the said check or bid bond shall be forfeited to Jackson County, Tennessee, as liquidated damages for the failure to do so. The successful bidder or bidders will be required to furnish an acceptable performance bond and payment bond each in the amount of one hundred percent (100%) of the Contract price. Liquidated damages in the amounts set out in the Specifications and Contract Documents will be assessed for failure to complete the work within the contract completion time as specified herein. The bidder shall submit an affidavit stating that he as a company has a drug and alcohol testing program at least as stringent as that of the program operated by the governmental entity. All as required by the Tennessee Drug-Free Workplace Act. A copy of the owners program is available for review at either the Owners office or the Engineers office. The Owner reserves the right to reject any and all bids, and to waive any informalities, and to negotiate with any and all bidders. No bidder may withdraw his bid within sixty (60) days after the actual date of the opening thereof. Joseph Wayne NapierNotice is hereby given that on the 27th day of February 2025, letters testamentary were issued to the undersignedby the Probate Court of Jackson County, Tennessee in respect of the estate of Joseph Wayne Napier, who died November 8, 2024.All persons, resident and nonresident, having claims, matured or unmatured, against the estate are required to filethe same with the clerk of the above-named court on or before the earlier of the following dates, otherwise theirclaims will be forever barred:(A) Four (4) months from the date of the first publication (or posting of this notice if the creditor received an actual copy of this notice to creditors at least sixty (60) days before the date that is four (4) months from the date of thefirst publication; or(B) Sixty (60) days from the date the creditor received an actual copy of the notice to creditors if the creditorreceived the copy of the notice less than sixty (60) days prior to the date that is four (4) months from the date offirst publication as described in (1)(A); orTwelve (12) months from the decedent's date of death.This the 27th day of February, 2025.Joshua Napier, Personal RepresentativeSherrie Pippin Loftis, Clerk and MasterKayla Collins Cantrell, Attorney for Estate3-4, 3-11 2TPSTATE OF TENNESSEEPROBATE COURT OF JACKSON COUNTY AT GAINESBORONOTICE TO CREDITORSESTATE OF: Edna Merle MarleyNotice is hereby given that on the 28th day of February 2025, Letters of Testamentary, in respect to the estate ofEdna Merle Marley deceased, who died October 29, 2024, were issued to the undersigned by the Probate Court ofJackson County, Tennessee.All persons, resident and non-resident, having claims, matured or unmatured, against the estate are required to filethe same with the Clerk of the above named Court at the Jackson County Court House, P.O. Box 342, Gainesboro,TN 38562 within the earlier of four (4) months from the date of the first publication of this notice, or twelve (12)months from the decedent's date of death, otherwise their claims will be forever barred.