Paving for a retail development in Jacksonville, North Carolina. Completed plans call for paving for a retail development.

The City of Jacksonville is requesting BIDS for RFB-Rotary Parking Lot Refinish located in Jacksonville, North Carolina: Description: Mill and repave the asphalt parking lots owned by the Rotary Club off of New Bridge St. This will include minimal grading, striping, and preparation of landscape areas to be completed by others. The responsibility for submitting bids (including all documents requested herein) is solely and strictly that of the bidder. The CITY is not responsible for delays in the delivery of the mail or delays caused by any other occurrence. Bids received after the time for closing will not be considered. EQUAL OPPORTUNITY: The City of Jacksonville is an Equal Opportunity Employer and Service Provider and encourages participation by small-, minority-, and female-owned firms. Bidders must make positive efforts to use Small or Minority Business enterprises. All qualified Small and Minority businesses are welcome to submit a bid. MINORITY BUSINESS PARTICIPATION: The CITY has established a verifiable goal of ten percent (10%) for minority participation on City building construction and repair projects. In order to foster participation by minority businesses to conduct business with the City and in accordance with NCGS 143-131(b) and Resolution 1994-08, the City of Jacksonville will solicit minority participation in all construction related contracts. Bidders shall undertake good faith efforts to recruit minority business participation on this project. The minority business must be registered with the North Carolina State Department of Administration, Office of Historically Underutilized Businesses. BIDDER must complete and submit either Affidavit A or B with their Bid proposal. DEFAULT AND ANNULMENT OF CONTRACT: If the Contractor fails to begin the work under Contract within the time specified, or fails to perform the work with sufficient employees and equipment or with sufficient materials to ensure the prompt completion of said work, or shall perform the work unsuitably, or shall neglect or refuse to remove materials or perform anew such work as shall be rejected as defective and unsuitable, or shall discontinue the work, or shall fail to resume the work which has been discontinued within a reasonable time after notice to do so, or if the Contractor shall become insolvent or be declared bankrupt, or commit any act of bankruptcy or insolvency, or allow any final judgment to stand against him unsatisfied for a period of ten (10) days, or shall make an assignment for the benefit of creditors, or from any other cause whatsoever shall not carry on the work in an acceptable manner, the City shall give notice in writing to the Contractor and his/her Surety of such delay, neglect, or default, specifying the same. If the Contractor or Surety, within a period of ten (10) days after such notice, shall not proceed in accordance therewith, then the Owner shall upon written notification from the Engineer of the fact of such delay, neglect, or default and the Contractor's failure to comply with such notice, have full power and authority, without violating the Contract, to take the prosecution of the work out of the hands of said Contractor. The Owner may appropriate or use any or all materials and equipment on the ground as may be suitable and acceptable and may enter into an agreement for the completion of said Contract according to the terms and provisions thereof, or use such other methods as in his/her opinion shall be required for the completion of said Contract in an acceptable manner. All costs and charges incurred by the Owner together with the costs of completing the work under Contract shall be deducted from any monies due or which may become due said Contractor. In case the expense so incurred by the Owner shall be less than the sum which would have been payable under the Contract if it had been completed by said Contractor, then the said Surety shall be entitled to receive this difference, and in case such expense shall exceed the sum which would have been payable under the Contract, then the Contractor and the Surety shall be liable and shall pay to the Owner the amount of said excess. If you have any questions, or if you would like the complete bid document, please contact MORGAN WESTBROOK, PROJECT MANAGER, City of Jacksonville, Email: mwestbrook@jacksonvillenc.gov at (910) 938-5074 or TDD (910) 455-8852 Locations: 206 CANTERBURY DRIVE JACKSONVILLE, NC 28540 800 NEW BRIDGE STREET JACKSONVILLE, NC 28540