Demolition, site work and renovation of a municipal facility in Tuscaloosa, Alabama. Completed plans call for the renovation of a 22,000-square-foot municipal facility; for the demolition of a municipal facility; and for site work for a municipal facility.

The Project will include the demolition and reconstruction of +-22,000 SF of courtrooms, offices, and ancillary spaces. The Project will consist of abating existing hazardous materials within the project area; updating existing mechanical, electrical, and plumbing systems to support the new functions of the space; and bringing these systems up to current code. New additions to both floors will include an additional courtroom and family restroom on each floor, and interior design work will include an updated courtroom design, new millwork for all courtrooms, and updated finishes throughout the two floors. The Alabama Department of Corrections is contracted with the Owner to refinish existing millwork that is being reused and to construct all new millwork and wood paneling in the courtrooms, so the bidder will need to coordinate with DOC. All work on site will need to occur outside of the courthouse's weekday business hours (Monday through Friday from 8:30 a.m. to 5 p.m.) or on weekends. The Project will be divided into four (4) phases to accommodate new judges taking office in 2027 and 2029. The first phase must be complete no later than January 8, 2027. A cashier's check or Bid Bond payable to the Tuscaloosa County Commission in an amount of not less than five (5) percent of the amount of the proposal, but in no event more than $10,000, must accompany the bid. Performance and Statutory Labor and Material Payment Bonds in the amount of 100% of the Contract Price will be required at the signing of the Contract. Any permits, licenses, or fees required by any governmental agency will be furnished and paid for by the Contractor. All costs for business licenses required by the governing authorities shall be the responsibility of the General Contractor. Applicants are to submit their response packages electronically to CMH, attention Billy Morace and Blake Nelson, no later than end of business (5:00 p.m. CT) on December 8, 2025, and confirm receipt thereof by phone and email. Submittals will be reviewed and either approved or rejected by representatives of the Tuscaloosa County Commission and CMH Architects, prior to documents being released for bidding to those Contactors deemed qualified (approved). Prequalified General Contractors will be notified no later than end of business (5:00 p.m. CT) on December 18, 2025. Liquidated Damages do apply to this project in the amounts specified in the Supplemental General Conditions section of the Specifications. No bid may be withdrawn after the scheduled closing time for the receipt of bids for a period of sixty (60) days. Only bids submitted by Prequalified General Contractors licensed as required by applicable State and local laws and bearing the license number of the Contractor will be considered. The Owner reserves the right to reject any or all bids; to waive formalities and technicalities; and to proceed in its own best interests. Performance Time: Phase One has a critical completion date of no later than January 8, 2027. The following three phases shall each last approximately 10 months each, with the full project being complete by June 30, 2029. Liquidated Damages do apply to this project in the amounts specified in the Supplemental General Conditions section of the Specifications. No bid may be withdrawn after the scheduled closing time for the receipt of bids for a period of sixty (60) days. Only bids submitted by Prequalified General Contractors licensed as required by applicable State and local laws and bearing the license number of the Contractor will be considered.