Site work and new construction of a civil project in Vacaville, California. Completed plans call for the construction of a water / sewer project; and for site work for a water / sewer project.

The general description of work includes: This project involves work at three distinct sites: Well 18, Well 19, and Well 20. At Well 20, the project includes the installation of site fencing and the construction of CMU block buildings to house all chemical and electrical equipment. At Wells 18 and 19, sound walls will be installed, and a CMU block building will also be constructed to house chemical and electrical equipment. Additionally, the project includes connecting to existing water, sewer, and storm drain systems at Well 18, and to existing water and storm drain systems at Wells 19 and 20. For Well 19, the Contractor shall coordinate with the separate waterline contractor on Midway Road to connect the well to the City's distribution system, including scheduling, utility locates, tie-ins, and testing to ensure seamless integration without delays. Coordination costs shall be incidental to related bid items. Wells 19 and 20 will also feature detention basins with lift stations. Furthermore, the work encompasses underground utilities, above-ground site features, wellhead appurtenances, chemical feed systems, electrical and instrumentation coordination, and SCADA integration. Question Deadline 02/23/2026 at 5:00 PM PT The Contractor shall possess licenses, or a combination of licenses required for the performance of the work. Contractor and subcontractors, if any, shall possess a Class A license at the time a bid is submitted for this Project. This Contract is subject to State Contract Nondiscriminatory and Compliance Requirements pursuant to California Government Code, commencing with Section 12900 through Section 12996. Bids are required for the entire work described herein. Refer to Part B of the Instructions to Bidders for Payment and Performance Bond Requirements. The successful Bidder shall furnish a Payment Bond and a Performance Bond in the amount of 100% of the Contract within ten (10) calendar days, not including Saturdays, Sundays, and designated Legal Holidays, after date of the Notice of Award letter. The Contractor May Elect to Receive 100% of Payments Due Under the Contract Document From Time to Time, Without Retention From Any Portion of the Payment by the City, by Depositing Securities of Equivalent Value of the Retained Amount With the City in Accordance With the Provisions of Section 22300 of the Public Contract Code. Such Securities, if Deposited by the Contractor, Shall Be Valued by the City, Whose Decision on Valuation of the Securities Shall Be Final. Securities Eligible for Investment Under This Provision Shall Be Limited to Those Listed in Section 22300 of the Public Contract Code and Section 16430 of the California Government Code. The Contractor Shall Indemnify and Hold Harmless the City From Any and All Loss or Damage Suffered by the City as a Result of Any Wrongful or Negligent Act or Omission on the Part of the Contractor or Any of Its Officers, Employees or Agents With Respect to the Performance for Escrow Agreement. The City Reserves the Right to Reject Any or All Bids, and to Determine Which Proposal is, in Its Judgment, the Lowest Responsive Bid of a Responsible Bidder and Which Proposal Should Be Accepted in the Best Interest of the City. The City Also Reserves the Right to Waive Any Irregularities in Any Proposal or Bid. Proposals in Which the Prices Are Obviously Unbalanced May Be Rejected. By Order of the Utilities Department Engineering Services Division, City of Vacaville