Renovation of a mixed-use development in Salem, Oregon. Completed plans call for the renovation of a educational facility.

The project consists of small bus drop off, heating/ventilation system improvements, intercom system upgrades, kitchen improvements, courtyard and sidewalk improvements, restroom addition, safety and security improvements, and converting select classrooms into a DLC classroom. This bid is only open to small general contractors prequalified under RFP 395 and Pre-Qualified Built Up Roofers under RFP 396 and Pre-Qualified Composition Roofers under RFP 397. Contractors may contact the Construction Services office to verify their status. No bid will be received or considered unless the Bid contains a statement by the bidder certifying, as part of the bid, compliance with the provisions required by ORS 279C.800 to 279C.870 (Prevailing Wage Rate). Pursuant to ORS 279C.365, no bid for a construction contract shall be received or considered by the public contracting agency unless the bidder is registered with the Construction Contractors Board or licensed by the State Landscape Contractors Board. Contractors and sub-contractors performing any asbestos abatement work are to be licensed by the Department of Environmental Quality as provided in ORS 468A.700-468A.760. No bid will be received or considered by the District unless the bid contains a statement as to whether the bidder is a resident bidder, as defined in ORS 279A.120. No proposal will be considered unless accompanied by bid security in the form of a surety bond executed by a State licensed surety company, payable to the Salem-Keizer School District 24J in an amount equal to ten percent (10%) of the Base Bid. No interest will be paid on bid security. Return or retention of bid security shall be subject to the provisions of ORS 279C.385. Pursuant to ORS 279C.395 the School District may reject any bid not in compliance with all prescribed bidding procedures and requirements and may reject for good cause any or all bids if, in the judgment of the Board of Directors, it is in the public interest to do so. The School District shall have the right to waive informalities and to reject any or all bids and in particular to reject a bid not accompanied by any required bid security or data required by the Bidding Documents. No bidder may withdraw their bid after the hour set for the opening thereof and before award of the Contract, unless award is delayed beyond sixty (60) days from the bid opening date. The District reserves the right to consider unusual or extenuating circumstances.