Site work for a water / sewer project in Dayton, Ohio. Working plans call for site work for a water / sewer project.

*As of 07/21/2023, no qualifications were submitted.* The project is a part of a larger project to enhance the County's "Emergency Water Supply" plan. To meet this objective; portable emergency water equipment was purchased for any event requiring emergency access to water. Types of equipment purchased included 17 portable water bladders, 4 water trailers, 5 water event stations, 2 over head filling stations (J stands), 20 valve actuators, and all associated fittings for all equipment. This equipment allows us to build a potable water tank farm, build multiple site potable tank farms, isolate water towers and feed only hospitals to support our most critical customers during such an event. It is imperative that a facility is built to support the storage and protection of this equipment during non-use. The scope of Design-Builder services as described herein provides a general description of the services Owner anticipates requiring of the Design-Builder for execution of the Project. It should be understood and anticipated that Owner will continue to enhance and expand on the description of services through development of the RFP and beyond, such that the final scope of services may not be determined until after selection of the Design-Builder and the negotiation of the Progressive Design-Build Contract. Deadline for Questions July 12, 2023 (5:00 pm local time) The Board of County Commissioners, Montgomery County (Owner) hereby requests Statements of Qualifications (SOQs) from interested firms, that can demonstrate, in accordance with the requirements of this Request for Qualifications (RFQ), the legal, technical, and financial capability to provide design, construction, and other related services in connection with the Environmental Services Water Storage Facility. The Project shall be designed and constructed in two phases using the Progressive Design-Build (PDB) delivery methods, which will be further defined in the Request for Proposals (RFP) and the Contract Documents and as follows: o Phase I: The selected Design-Builder shall work with Montgomery County Facilities Management (MCFM) and Montgomery County Environmental Services (MCES) to develop the design to a 60% level of design completion and propose a Guaranteed Maximum Price (GMP), along with a detailed breakdown of estimated construction costs and a proposed schedule. o Phase II: Upon acceptance by MCFM and MCES of the proposed design and GMP, the selected Design- Builder shall complete design, construction, and post-construction tasks. The Project is not being executed as the result of regulatory or other compliance requirements. MCES has established a preliminary design concept for the Project along with target completion dates for certain milestones. MCES/MCFM will also consider other design concepts that accomplish the same basic functional goals as the preliminary design concept, as well as alternative schedule milestones as may be proposed through the Design-Build procurement process and Phase I of the design by the selected Design-Builder. SOQ packages must be clearly marked: "PP-1191 Water Storage Facility SOQ" with the Respondent's name and address. Each Respondent assumes full responsibility for the timely delivery of its SOQ at the location indicated above. Any SOQ packages received after the designated submittal deadline may be deemed nonresponsive and returned unopened. Montgomery County reserves all rights to waive any informalities, irregularities, or technical defects in the responses to this RFQ.