Renovation of a mixed-use development in Auburn, Washington. Completed plans call for the renovation of a educational facility.

Demolition of existing receptacles, as noted in project drawings, and extend circuit with new receptacle at LFD location. Provide extension box and blank faceplate at existing receptacle location, unless otherwise noted. Work will include installation of Owner-Furnished LFDS, mounts, and other tertiary technology. Bids received after the time fixed above for receiving bids cannot be considered. A certified check, a bank cashier's check, or a bid bond executed by a State licensed surety company and payable to the Auburn School District #408 is required with each bid, in an amount equal to five percent (5%) of the Base Bid. Pursuant to RCW 39.12, no worker, laborer, or mechanic employed in the performance of any part of this contract shall be paid less than the "Prevailing Rate of Wage" (in effect as of the date the bids are due) as determined by the Industrial Statistician of the Department of Labor and Industries. The Owner shall have the right to reject any or all bids for any reason or for no reason, to reject a Bid not accompanied by required bid security or by other data required by the Bidding Documents, or to reject a Bid which is in any way incomplete or irregular. The Owner shall have the right to waive any informality or irregularity in any Bid or Bids received and to accept the Bid or Bids which, in its judgment, is in its own best interests. The Bid, bid security, and any other documents required to be submitted with the Bid shall be enclosed in a sealed opaque envelope identified with the Project name and the Bidder's name and address. A bid may not be withdrawn after the stated time and date for opening thereof or before award of Contract, unless said award is delayed for a period exceeding 45 calendar days from the date of bid opening. If a specific time period is required for completion or delivery of the contract, it will be so stated in the bid documents. Date of delivery/completion stated in the bid documents shall become a part of this contract. Questions regarding this bid shall be directed to the Engineer. The Auburn School District Board of Directors reserves the right to reject any or all bids for any reason or for no reason, to reject a Bid not accompanied by required bid security or by other data required by the Bidding Documents, or to reject a Bid which is in any way incomplete or irregular. The Owner shall have the right to waive any informality or irregularity in any Bid or Bids received and to accept the Bid or Bids which, in its judgment, is in its own best interests. Bids will be accepted only from contractors who are licensed or registered according to the laws of the State of Washington. Prospective Bidders and Subcontractors may schedule visits to the project site by calling the Auburn School District Capital Projects Department at 253-931-4826. Questions from prospective bidders regarding the project and the existing facilities shall be submitted to the Architect at least seven (7) days prior to the Bid Date. Prospective bidders shall not direct questions to staff that are present at the administration building.