Demolition, site work and new construction of a mixed-use development in Centre, Alabama. Completed plans call for the demolition of a educational facility; for the construction of a 8,300-square-foot municipal facility; for site work for a educational facility; municipal facility; and water / sewer project.

As of June 12, 2024 this project was awarded to Commercial Construction & Maintenance Inc with the awarded amount of $4,135,053.80. Scope of Work includes but is not limited to, construction of the new facility located on the City's Property at 350 E. Main Street, Centre, AL. The Work generally consists of site utilities relative to tying in the new building to existing sanitary, gas, electric and water services, site improvements relative to new construction, utility improvements, demolition of the existing Centre Middle School and other existing onsite buildings indicated, New work will consist of, but is not limited to, structural steel framing, metal stud in-fill, metal stud and drywall partitions, masonry veneer, light-gage metal roof trusses, composition shingle roofing, soft tile and hard tile floor finishes, lay-in and gyp. board ceilings, hollow metal doors and frames, prefinished wood doors, hardware, HVAC, Electrical, toilet compartments and toilet accessories, mobile file system, casework/millwork and new commercial kitchen facilities. Facility size is approximately 8,300 s.f. A cashier's check or bid bond payable to the City of Centre, in an amount not less than five (5) percent (maximum $10,000.00) of the amount of the bid must accompany the bidder's proposal. Performance and Payment Bonds and evidence of insurance required in the bid documents will be required at the signing of the Contract. The successful bidder will be required to furnish and pay for the satisfactory Performance and Payment Bond or Bonds in the amount required by Section 39-1-1(a), Code of Alabama 1975, and evidence of insurance as required by the bid documents within ten (10) days after being notified that he has been awarded the contract. General Contractors who obtain bid documents and wish to withdraw from the Official Bidders List must do so in writing to the Architect prior to the bid date. Bids received from General Contractors who are not on the Official Bidders List will not be accepted or opened. Thomas M. McElrath, Architect, makes no guarantee of bid documents obtained by Contractors and Vendors from sources other than the issued documents provided by the Architect. Contractors and Vendors who base their pricing from bid documents obtained otherwise, either in part or whole, do so at their own risk. CONSTRUCTION DURATION: The Contractor shall commence the Work on or before the date established in the written Notice to Proceed, and shall complete the Work within Four Hundred Eighty (480) consecutive calendar days thereafter. LIQUIDATED DAMAGES for which the Contractor and its Surety (if any) shall be liable and may be required to pay the Owner in accordance with the Contract Documents shall be equal to six percent interest per annum on the total Contract Sum. Bids must be submitted on proposal forms furnished by the Architect or copies thereof. The Owner reserves the right to reject any or all proposals and to waive technical errors if, in the Owner's judgment, the best interests of the Owner will thereby be promoted.