Site work for a water / sewer project in West Valley City, Utah. Completed plans call for site work for a water / sewer project.

Utilities including gas and power and water and sewer and electricity and utilities management and consulting services, and alternative forms of energy, solar panels and servicing . Electrical wire and cable and harness including conduit and fittings and circuit breakers .Hand tools including clamping and masonry and fastener and cutting and finishing and power tools and wrenches and drivers. Rehabilitation of the East Recreation Lift Station sewer vault. Work includes installing blast cleaning and installation of new epoxy coating. Removal, cleaning and reinstalling the internal equipment and platforms. Installing new light fixtures, replacing electrical conduits and sonic level sensor. Work requires bypass pumping. Project Budget - $245,000.00 The Work will be Substantially Completed 175 calendar days after the date of the Notice to Proceed. Owner Rights: The OWNER reserves the right to reject any or all bids or to waive any informality or technicality in any bid if deemed to be in the best interest of the OWNER. The Owner reserves the right to reject any or all bids and to determine which bid is, in the Owner's judgment, the lowest responsive responsible bid of a bidder or group of bidders. The Owner also reserves the right to waive any informality in any bid and to delete certain items listed in the bid as set forth therein. Bond Notes: Bid security in the amount of five percent (5%) of the Bid must accompany each Bid in accordance with the Instructions to Bidders. Bid Security will be returned to each unsuccessful Bidder after tabulation and award of the Construction Contract. The successful bidder will be required to furnish performance and payment bonds, each in an amount not less than one hundred percent (100%) of the contract price. Liquidity Damages: Time is the essence of the Contract Documents. CONTRACTOR agrees that OWNER will suffer damage or financial loss if the Work is not completed on time or within any time extensions allowed in accordance with Part 12 of the General Conditions. CONTRACTOR and OWNER agree that proof of the exact amount of any such damage or loss is difficult to determine. Accordingly, instead of requiring any such proof of damage or specific financial loss for late completion, CONTRACTOR agrees to pay the following sums to the OWNER as liquidated damages and not as a penalty. Late Contract Time Completion: One Thousand Dollars ($1,000.00) for each day or part thereof that expires after the Contract Time until the Work is accepted as Substantially Complete as provided in Article 14.5 of the General Conditions. The work to be performed consists of furnishing and installing the facilities and appurtenances thereto as included in the Contract Documents. The Work generally includes, but is not limited to, the following: 1. Obtaining all permits. 2. Project supervision. 3. Mobilization/Demobilization. 4. Rehabilitation of the East Recreation Lift Station sewer vault. Work includes installing blast cleaning and installation of new epoxy coating. Removal, cleaning and reinstalling the internal equipment and platforms. Installing new light fixtures, replacing electrical conduits and sonic level sensor. Work requires bypass pumping. 5. Installation of an impressed current cathodic protection system including rectifier, deep well anode bed, and connection to existing lift station. D. For information about the award of this Construction Contract, contact: Granger-Hunter Improvement District 2888 South 3600 West West Valley City, Utah 84119 Attention: Victor Narteh, P.E. Phone: 801-955-2247 Question Submission Close Date 4/24/2024 3:00 PM MDT