Site work and paving for a road / highway in Santaquin, Utah. Completed plans call for site work for a road / highway; and for paving for a road / highway.

utah county 5200 west road improvements Through this Invitation to Bid (ITB), Utah County intends to select a contractor to provide for the construction and completion in every detail of "5200 West Road Improvements" within Utah County as per the specifications, plans and the Drawings included in or referenced in this ITB. All questions regarding this ITB must be submitted through Electronically . The deadline for submission of questions is before 5pm at least two business days prior to the submission date. The County Project Manager for this project is listed below: County Project Manager Contact County Project Manager Logan Gurr Office Phone No. (801) 851-8620 Cell Phone No. (385) 283-9586 Email Address logang@utahcounty.gov. A. Before this contract is awarded by Utah County, the Contractor shall furnish to Utah County the following bonds: 1. A performance bond satisfactory to County in an amount equal to 100% of the price specified in the contract, to assure the faithful performance of the contract, for the protection of Utah County, to be held until final acceptance by Utah County of all aspects of this project; and 2. A payment bond satisfactory to the County in an amount equal to 100% of the price specified in the contract, for the protection of each person supplying labor, service, equipment, or material for the performance of the work provided for in the contract. B. Each bond shall be: 1. Binding upon the award of the contract; 2. Executed by a surety company or companies duly authorized to do business in the State of Utah, or, in the form or cash or other certified funds. 3. Payable to Utah County, A Body Corporate and Politic; 4. Filed with the Utah County Public Works Department in a timely manner following the Closing date for Receipt of Bids, and 5. Increased if the contract price is increased by change order or otherwise subsequent to entering into the contract. C. Utah County will hold the Payment Bond for ninety (90) days subsequent to the completion of the project. The completion date for the 5200 West Road Improvements is on or before October 15, 2024, regardless of weather conditions and other related problems. If the Contractor fails to complete the work on or prior to the completion date, or by extension of time granted by the County in writing, then the Contractor may forfeit his or her 5% payment retainer and shall in addition be liable for all additional costs and damages incurred by Utah County as a result of the failure of completion. If abnormal weather conditions or other natural events totally beyond the control of the Contractor require in the judgment of the County an extension of the completion date, written authorization must be given by County for such specific extension. It is agreed by the parties to this Agreement that in case all the work called for in accordance with this Agreement is not completed before or upon the Completion Dates set forth in this Agreement, damage will be sustained by Utah County, and that it is and will be impracticable to determine the actual damage which Utah County will sustain in the event of and by reason of such delay, and it is therefore agreed that the Contractor will pay to Utah County $1860.00 per day for each calendar day between the Completion Date required herein for any specific roadway and the date of final acceptance thereof by Utah County, as liquidated damages and not as penalty. It is further agreed that the amounts stipulated are reasonable estimates of the damages that would be sustained by Utah County and the Contractor agrees to pay such liquidated damages as herein provided. In case the liquidated damages are not paid, the Contractor agrees that Utah County may deduct the amount thereof from any money due to or that may become due the Contractor by progress payments or otherwise in accordance with the terms of this Agreement, or if said amount is not sufficient, recover the total amount. The Contractor will not be assessed with liquidated damages during any delay in the completion of the work caused by acts of God, acts of criminals, acts of Utah County, acts of the public utilities, fire, floods, epidemics, quarantine restrictions, labor strikes that delay the critical sequence of the work, and unusually severe weather or delays of subcontractors due to such causes, provided that Utah County is notified in writing of the causes of such delay.