Site work for a water / sewer project in Holland, Michigan. Completed plans call for site work for a water / sewer project.

The U.S. Army Corps of Engineers (USACE) Detroit District intends to solicit for Holland Inner Harbor Maintenance Dredging and Weir Repair, located in Holland, Michigan. The project s, but is not limited to mobilize to the Holland, Michigan Inner Harbor and dredge from STA 179+00 to 218+50 and from STA 284+00 to STA 311+00. Place dredged material as shown on the plans after completing pipe-lining weir repair as shown on the plans thus allowing for continued compliance with existing Water Quality Certification. Demobilize when dredging work is completed. The North American Industrial Classification System (NAICS) code for this work is 237990 (Exception), Other Heavy and Civil Engineering Construction, which has a small business size standard of 37 million (dredging) in average annual receipts. The Information for Bid (IFB) is intended to be issued as a 100 for small businesses. General Information: The Government intends to issue a firm-fixed price contract. Magnitude of construction is between 500,000 and 1,000,000. The Contractor shall be to (a) commence work under this contract within 10 calendar after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than November 14th, 2025. The time stated for completion shall include final cleanup of the premises. The completion date is based on the assumption that the successful offeror will receive the notice to proceed by August 1, 2025. The completion date will be extended by the number of calendar after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the and s within the time specified in the offer. The amount of the bid guarantee shall be 20 percent of the bid price or 3,000,000.00, whichever is less. Performance bonds (Standard Form 25, except that no seal is ). The penal amount of performance bonds at the time of contract award shall be 100 percent of the original contract price. Payment bonds (Standard Form 25A, except that no seal is ). The penal amount of payment bonds at the time of contract award shall be 100 percent of the original contract price. The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States. The Contracting Officer will return bid guarantees, other than bid bonds- *The value for this project is based on a financial range. The value is listed as the highest possible cost from the range provided by a stakeholder or official project document.