Renovation of a theater / auditorium in Gilroy, California. Completed plans call for the renovation of a theater / auditorium.

The Architect will visit the Site at intervals necessary in the judgment of the Architect or as otherwise agreed by the Owner and the Architect in writing to become generally familiar with the progress and quality of the completed Work and to determine in general if the Work is being performed in a manner indicating that the Work, when Completed, will be in accordance with the Contract Documents. The items of work indicated below propose modifications to, substitutions for, additions to and/or deletions from the various parts of the Work specified in other Sections of the Specifications. The acceptance or rejection of any of the alternates is strictly at the option of the Owner subject to Owner's acceptance of Contractor's stated prices contained in this Proposal. Where an item is omitted, or scope of Work is decreased, all Work pertaining to the item whether specifically stated or not, shall be omitted and where an items is added or modified or where scope of Work is increased, all Work pertaining to that required to render same ready for use on the Project in accordance with intention of Drawings and Specifications shall be included in an agreed upon price amount. Any questions submitted outside PlanetBids and/or after the deadline of July 2, 2025 at 5 PM (PT) will not be considered. Theatre Roof Replacement. Q&A Deadline 07/02/2025 5:00 PM (PDT) Online. Bid Valid 90 DAYS Liquidated Damages $200 Per Calendar Day Estimated Bid Value $1,000,000.00 Start/Delivery Date Project Duration 60 DAYS License Requirements "B" LICENSE