Site work for a water / sewer project in Wewahitchka, Florida. Completed plans call for site work for a water / sewer project.

The project is located along the gulf front beach of St. Joseph Peninsula, Gulf County, Florida. The project consists of the construction of a dune enhancement project between DEP Monuments R-89.6 and R-105.5 extending from the Stumphole revetment to the north for 3.1 miles (16,254 feet). The project consists of the placement of clean white beach compatible sand obtained from the Honeyville Sand Mine in Wewahitchka, Florida totaling approximately 78,930 cubic yards. In addition, the project includes the installation of multiple native dune vegetation species totaling approximately 619,126 plants along the project shoreline. The Bidders are responsible for verifying all quantities. All bids shall remain firm for a period of sixty days after the opening. All Bidders shall comply with all applicable State and local laws concerning licensing registration and regulation of contractors doing business to the State of Florida. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes. Any questions must be submitted to Clay Smallwood, P.E. at csmallwood@gulfcounty-fl.gov. The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of Gulf County. Completion date for this project will be 120 days from the date of the Notice to Proceed presented to the successful bidder. Liquidated damages for failure to complete the project on the specified date will be set at $800.00 per day.