Site work for a water / sewer project in Wewahitchka, Florida. Completed plans call for site work for a water / sewer project.

**As of November 03, 2022, the award amount is not yet determined. The project consists of the construction of a dune project along the gulf front beaches of St. Joseph Peninsula, Gulf County, Florida, specifically between DEP Monuments R-77 and R-85.5 for approximately 8,750 linear feet (1.66 miles) of shoreline for a total template volume of 97,091 cubic yards (cy) of sand and 288,600 native dune plantings. The clean white beach compatible sand will be obtained from the Honeyville Sand Mine in Wewahitchka, Florida. The Bidders are responsible for verifying all quantities. Completion date for this project will be a total of 120-days from the date of the Notice to Proceed presented to the successful Bidder. Liquidated damages for failure to complete the project on the specified date will be set at $1,500.00 per day. Please place YOUR COMPANY NAME, ADDRESS, and "SEALED BID #2122-26" on the outside of your envelope and include the original bid plus 3 copies. All Bidders shall comply with all applicable State and local laws concerning licensing registration and regulation of contractors doing business to the State of Florida. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes. Any questions must be submitted to Clay Smallwood, P.E. at csmallwood@gulfcounty-fl.gov. The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of Gulf County.