Site work and paving for a civil project in Eastpoint, Florida. Completed plans call for site work for a road / highway; for paving for a road / highway; and water / sewer project.

As of September 6,2024, project was awarded to Pigott Asphalt And Site Sitework LLC, awarded amount is $517,865.20. The project is the widening and resurfacing of Hickory Dip Road for approximately 0.37 miles from Old Ferry Dock Road to Bayshore Drive. Other work to include necessary Drainage improvements, upgraded signage and pavement Marking and safety improvements. All bidders shall be FDOT qualified per Section 2-1 of the FDOT Standard Specifications for Road and Bridge Constructions, latest edition in the following work classes: Grading, Drainage, Flexible Paving, and Hot Plant mix-Bituminous Course. Completion date for this project will be 90 days from the date of the Notice to Proceed presented to the successful bidder. Liquidated damages for failure to complete the project on the specified date will be set at $750.00 per day. The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of Franklin County. All bids shall remain firm for a period of sixty days after the opening. All bidders shall comply with all applicable State and local laws concerning licensing registration and regulation of contractors doing business to the State of Florida. All technical questions must be addressed in writing and emailed to Josh Stephens at jstephens@dewberry.com no later than July 02, 2024.