Site work for a playground / park / athletic field in Crescent City, California. Completed plans call for site work for a playground / park / athletic field.

Deadline to submit written questions September 3, 2024 Responses to questions September 5, 2024 Contact Person: David Yeager, Public Works Director City of Crescent City 377 J Street Crescent City, CA 95531 (707) 464-9506 x234 dyeager@crescentcity.org The work includes the furnishing of the labor, materials, and equipment for the installation of concrete paving, curbs and decorative paving for the completion of the 1- mile loop, landscaping including soil preparation, vegetation, irrigation, fencing and site furnishings, and installation of outdoor fitness equipment all in accordance with the drawings and specifications. The project is located in Beachfront Park between the Northcoast Marine Mammal Center and the Crescent City Dog Town in Crescent City, CA. Qualifications: Contractor must be licensed as an (A) General Engineering Contractor by the California Contractors State License Board to bid on this project. Special Requirements: Full-size and half-size copies of the project manual may be obtained at City of Crescent City Public Works Department 377 J Street, Crescent City, CA 95531 ((707) 464-9506), upon payment of postage fees. Bidders must correctly prepare and submit the documents listed in Section 00 40 00, Bid. Each bid must be accompanied by a bid guaranty bond, or a certified or cashier's check payable to the order of the Owner in an amount not less than ten percent (10%) of the amount of the bid as a guaranty that the bidder will execute the contract if it is awarded in conformity with the bid form. The successful bidder will be required to furnish performance and payment bonds, each in an amount not less than one hundred percent (100%) of the contract price. At the successful Bidder's option, securities may be substituted for the required retention, in accordance with the provisions of Section 22300 of the State of California Public Contract Code. The Owner reserves the right to reject any or all bids and to determine which bid is, in the Owner's judgment, the lowest responsive bid of a bidder or group of bidders. The Owner also reserves the right to waive any informalities in any bid and to delete items listed in the bid. Bids received after the time established for receiving bids will not be considered. Except as provided in paragraph 00 20 10-1.04(A), no bidder may withdraw his bid after the time established for receiving bids or before the award and execution of the contract, unless the award is delayed for a period exceeding ninety (90) calendar days. Bidders are hereby notified that pursuant to Section 1773 et seq. of the Labor Code of the Statutes of the State of California, the Owner has obtained from the Director of the Department of Industrial Relations the general prevailing rate of wages and employer payments for health and welfare, vacation, pension, and similar purposes for work to be done within Del Norte County, California. Regulations regarding the application of these wage rates are given in paragraph 00 20 00-1.12. No contractor or subcontractor may be listed on a bid proposal for a public works project unless registered with the Department of Industrial Relations pursuant to Labor Code section 1725.5 [with limited exceptions from this requirement for bid purposes only under Labor Code section 1771.1(a)]. No contractor or subcontractor may be awarded a contract for public work on a public works project unless registered with the Department of Industrial Relations pursuant to Labor Code section 1725.5. This project is subject to compliance monitoring and enforcement by the Department of Industrial Relations. Bidders on this work must comply with all applicable governmental and local agency requirements.