Renovation of a water / sewer project in Thomasville, North Carolina. Completed plans call for the renovation of a water / sewer project.

This project is to replace the existing non-functional Liebert 5 Ton unit and air handler with one (1) 5-Ton Liebert PDX Air-Cooled Systems, Model PX018UA1AD. The new unit must be a Liebert unit so that it can communicate with the other Liebert unit that is in the same location. The existing Liebert air handler (AC 100) will be removed from the penthouse, and the Liebert condenser (CU 100) will be removed from ground level for equipment disposal. The existing refrigerant lines will be abandoned in place. The new air handler will be installed in the penthouse. The new condenser will be located outside of the penthouse onto an equipment pad. The Contractor is to provide all necessary equipment, tools, crane, and machinery to install a new working unit. The Attorney-in-fact who signs Bid Bonds or Contract Bonds must file with each Bond a certified and effectively dated copy of their Power of Attorney Prior to or at the time of the execution of the Agreement, the Contractor will provide a payment bond and a performance bond consistent with the statutory forms set forth in Chapter 44A of the North Carolina General Statutes (see N.C. Gen. Stat. 44A-33) and the forms set forth in the Contract Documents. The payment bond and the performance bond are required to ensure the Contractor's full and proper performance of the Work and the Contractor's full and prompt payment of all subcontractors and suppliers providing labor or materials relating to the Work. The surety on the payment bond and the performance bond, by providing these bonds, agrees to be bound by the terms of the Agreement, and agrees to perform any action and make any payment required under the Agreement that the Contractor fails to perform or make. In light of the difficulty of making a precise determination of such damages, the City and the Contractor agree that the sum of Five Hundred Dollars ($500.00) per day (or any part thereof) will be charged against the Contractor, not as a penalty, but as liquidated damages Questions concerning this bid are due in writing via email by: April 8, 2025 by 12:00 PM to the attention of Libby Rush at libby.rush@highpointnc.gov Days to Complete the Work. The completion date for this contract shall be 90 consecutive calendar days to complete the work beginning with the Notice to Proceed Date. The City reserves the right to reject any and all bids, as may in the judgment of the City, serve its best interest and the City further reserves the right to waive irregularities and informalities in any bid submitted.