Site work and paving for a mixed-use development in Orange Park, Florida. Completed plans call for site work for a playground / park / athletic field; sidewalk / parking lot; and for paving for a sidewalk / parking lot.

The Clay County Board of County Commissioners (County) is requesting bids from qualified Contractors for improvements at Moody Avenue Park The Contractor shall supply all labor, materials (except for concrete) and equipment for constructing a reinforced concrete slab, sidewalks, and site improvements. Major Concrete, LLC shall supply the concrete material, while the Contractor shall be responsible for coordinating its delivery. Fitness Court and Fitness Court Studio Add-On shall be installed by others. Question Deadline 09/26/2025 at 4:30 PM ET For questions about Clay County permitting please contact: Clay County Building Department Phone: (904) 269-6307 Email: permits@claycountygov.com The original Cashier or Certified Check must be received by the Purchasing Department no later than two (2) business days after the RFB due date. Final Addendum: September 29, 2025, 4:30pm Original Cashier or Certified Check: October 8, 2025, 4:00pm Submittal Review :October 9, 2025 Bids require a five (5%) percent bid bond and may not be withdrawn after the scheduled opening time for a period of thirty (30) days. The term bid bond shall include bonds or cashier or certified checks payable to the County. Performance and Payment Bonds are not required for projects of $200,000.00 or less. Prior to commencement of a project exceeding $200,000.00, in accordance with F.S. 255.05, the awarded Bidder shall file a 100% Performance Bond and Payment Bond (using Clay County's Standard Form) in the Public Record of Clay County, Florida, Recording Dept./Room 130, 825 North Orange Avenue, Green Cove Springs, Florida 32043. The recorded Performance and Payment Bonds shall be provided prior to the commencement of construction to Clay County Purchasing Department, PO Box 1366, Green Cove Springs, Florida 32043. Performance and Payment Bonds must be increased in accordance with any change order increases on the project. The Contractor shall be assessed Liquidated Damages (LD) of $100.00 for each day past final completion date set by the contract. The Board reserves the right and power to reject any and all Bids without cause and to waive technical and non-technical or non-material defects in the Request for Bids or submittal of any Bid, and in its discretion to re-advertise the Request for Bids. The Board reserves the right to award Request for Bids which would be in the Best Interest of the County. Interested vendors are advised that the Clay County Board of County Commissioners has a local preference policy and Buy American policy The County reserves the right to request any additional information from Bidders after Bid Opening and before award as it may be necessary to assist in review and evaluation of any Bid prior to submittal of a recommendation for award to the Board of County Commissioners. The County reserves the right to make an award either in part or completely, and/or to accept the bid that, in its judgment, will be in the best interest of the County; providing best value to the County with price, technical, and other applicable factors considered. The County Reserves the right to award to multiple Bidders.